2024版机场航站楼铝合金门窗系统设计与施工合同

甲方：XXX乙方：XXX20XXCOUNTRACTCOVER专业合同封面RESUME甲方：XXX乙方：XXX20XXCOUNTRACTCOVER专业合同封面RESUMEPERSONAL

2024版机场航站楼铝合金门窗系统设计与施工合同本合同目录一览第一条合同主体及定义1.1设计方主体1.2施工方主体1.3甲方主体1.4乙方主体第二条设计与施工内容2.1设计内容2.2施工内容2.3设计与施工协调第三条合同金额与支付方式3.1合同金额3.2支付方式3.3进度付款3.4变更付款第四条设计与施工期限4.1设计期限4.2施工期限4.3延期规定第五条质量标准与要求5.1设计质量标准5.2施工质量标准5.3验收标准第六条技术与资料交换6.1设计资料提供6.2施工资料提供6.3技术与资料协调第七条变更与调整7.1变更程序7.2变更费用7.3变更执行第八条违约责任8.1设计方违约8.2施工方违约8.3甲方违约8.4乙方违约第九条争议解决9.1协商解决9.2调解解决9.3仲裁解决9.4法律途径第十条保险责任10.1设计方保险10.2施工方保险10.3甲方保险10.4乙方保险第十一条合同的生效、变更与终止11.1合同生效条件11.2合同变更程序11.3合同终止条件第十二条保密条款12.1保密内容12.2保密期限12.3泄露后果第十三条环境影响与安全13.1环境影响评估13.2安全生产措施13.3应急预案第十四条其他条款14.1不可抗力14.2法律适用14.3争议解决14.4附件说明第一部分：合同如下：第一条合同主体及定义1.1设计方主体designatingbody：指根据本合同规定负责铝合金门窗系统设计的服务提供方。1.2施工方主体constructionbody：指根据本合同规定负责铝合金门窗系统施工的服务提供方。1.3甲方主体partyA：指委托设计方和施工方进行铝合金门窗系统设计与施工的法人或其他组织。1.4乙方主体partyB：指设计方和施工方的法人或其他组织。第二条设计与施工内容2.1设计内容designcontent：包括铝合金门窗系统的设计方案、施工图纸、技术说明、材料清单等。2.2施工内容constructioncontent：包括铝合金门窗系统的安装、调试、验收等施工过程。2.3设计与施工协调designandconstructioncoordination：设计方和施工方应保持密切沟通，确保设计与施工的顺利进行。第三条合同金额与支付方式3.1合同金额contractamount：双方根据设计和施工内容商定的合同金额，具体金额在合同附件中详细列明。3.2支付方式paymentmethod：甲方按照设计和施工进度，分阶段支付合同金额。具体支付方式在合同附件中详细列明。3.3进度付款progresspayment：甲方根据设计和施工进度，按照合同约定的比例支付合同金额。3.4变更付款changepayment：如合同内容发生变更，双方根据变更金额商定支付方式。第四条设计与施工期限4.1设计期限designperiod：设计方根据合同约定完成设计任务的时间，具体期限在合同附件中详细列明。4.2施工期限constructionperiod：施工方根据合同约定完成施工任务的时间，具体期限在合同附件中详细列明。4.3延期规定delayregulations：如因不可抗力等原因导致设计和施工进度延误，双方根据实际情况商定延期期限。第五条质量标准与要求5.1设计质量标准designqualitystandards：设计方应按照合同约定的技术要求、规范和标准完成设计任务，确保设计质量。5.2施工质量标准constructionqualitystandards：施工方应按照合同约定的技术要求、规范和标准完成施工任务，确保施工质量。5.3验收标准acceptancestandards：双方按照合同约定的验收规范和标准进行验收，确保工程质量符合要求。第六条技术与资料交换6.1设计资料提供designinformationprovision：设计方应按照合同约定的时间和方式向施工方提供设计资料，包括设计方案、施工图纸等。6.2施工资料提供constructioninformationprovision：施工方应按照合同约定的时间和方式向设计方提供施工资料，包括施工进度、施工情况等。6.3技术与资料协调technologyandinformationcoordination：双方应保持密切沟通，及时解决设计和施工过程中遇到的问题，确保工程顺利进行。第八条违约责任8.1设计方违约8.2施工方违约8.3甲方违约8.4乙方违约第九条争议解决9.1协商解决ThepartiesshallfirstresolveanydisputesarisingoutoforinconnectionwiththisContractthroughfriendlynegotiation.9.2调解解决Ifthedisputescannotberesolvedthroughnegotiation,eitherpartymaysubmitthedisputestoapeople'scourtwithjurisdictionattheplaceofperformanceofthemaincontractortoanarbitrationinstitutionagreedthepartiesforarbitration.9.3仲裁解决Ifthepartieshaveagreedtoarbitrate,thedisputesarisingoutoforinconnectionwiththisContractshallbesubmittedtotheChinaInternationalEconomicandTradeArbitrationCommission(CIETAC)forarbitrationinaccordancewithitsrules.9.4法律途径Ifthepartiesareunabletoresolvethedisputesthroughnegotiationorarbitration,theymayresorttolegalproceedingsinthePeople'sCourtofthePeople'sRepublicofChina.第十条保险责任10.1设计方保险10.2施工方保险10.3甲方保险10.4乙方保险第十一条合同的生效、变更与终止11.1合同生效条件11.2合同变更程序AnyamendmentormodificationofthisContractmustbemadeinwritingandexecutedthepartieshereto.11.3合同终止条件第十二条保密条款12.1保密内容12.2保密期限ThepartiesshallmaintaintheconfidentialityoftheConfidentialInformationforaperiodof[insertperiod]yearsfromthedateofthisContract.12.3泄露后果IfthereceivingpartybreachesthisSection,itshallbeliabletothedisclosingpartyforalldamages,losses,orexpensessufferedorincurredthedisclosingpartyasaresultofsuchbreach.第十三条环境影响与安全13.1环境影响评估Thepartiesshallcarryoutanenvironmentalimpactassessmentinaccordancewithapplicablelawsandregulationsandtakenecessarymeasures第二部分：第三方介入后的修正第十四条第三方介入14.1定义ForthepurposesofthisContract,"ThirdParty"meansanyindividual,entityororganizationthatisnotthepartiestothisContractandisinvolvedintheperformanceofthisContract.14.2第三方责任TheThirdPartyshallberesponsiblefortheperformanceofthetasksassignedtoitunderthisContractandshallbeliableforanydirectlossescauseditsbreachofcontractornegligence.14.3第三方选择Thepartiesmay,attheirsolediscretion,selectaThirdPartytoperformcertaintasksunderthisContract.TheselectionofaThirdPartyshallbesubjecttothepriorwrittenconsentoftheotherparty.14.4第三方支付ThepartiesshallberesponsiblefornegotiatinganddeterminingthepaymenttermsfortheservicesprovidedtheThirdParty.ThepaymenttermsshallbesetforthinwritingandattachedasanannextothisContract.14.5第三方责任限额TheliabilityoftheThirdPartyunderthisContractshallbelimitedtotheextentspecifiedintherelevantannexorattachmenthereto.第十五条额外条款及说明15.1第三方义务TheThirdPartyshallbeboundthetermsandconditionsofthisContractandshallperformitsobligationsinaccordancewiththerequirementsoftheparties.15.2第三方与甲乙方的关系TheThirdPartyshallhavenorelationshipwiththepartiestothisContractotherthanasprovidedforinthisContract.15.3第三方违约处理IntheeventofabreachofcontractordefaulttheThirdParty,thepartiesshallhavetherighttotakelegalactionagainsttheThirdPartyinaccordancewiththetermsofthisContract.15.4第三方权利限制TheThirdPartyshallnothaveanyrightsunderthisContractotherthanthoseexpresslyprovidedforinthisContract.15.5第三方解除合同TheThirdPartymaynotterminatethisContractunlessthepartiesagreeinwritingtosuchtermination.第十六条第三方概念与责任划分16.1第三方概念ForthepurposesofthisContract,"ThirdParty"meansanyindividual,entityororganizationthatisnotthepartiestothisContractandisinvolvedintheperformanceofthisContract.16.2第三方责任划分TheThirdPartyshallberesponsiblefortheperformanceofthetasksassignedtoitunderthisContractandshallbeliableforanydirectlossescauseditsbreachofcontractornegligence.ThepartiesshallnotbeliableforanyactsoromissionsoftheThirdParty.16.3第三方与甲乙方的关系划分TheThirdPartyshallhavenorelationshipwiththepartiestothisContractotherthanasprovidedforinthisContract.ThepartiesshallnotberesponsibleforanyactsoromissionsoftheThirdParty.16.4第三方违约处理划分IntheeventofabreachofcontractordefaulttheThirdParty,thepartiesshallhavetherighttotakelegalactionagainsttheThirdPartyinaccordancewiththetermsofthisContract.Thepartiesshallnotbeliableforanylossessufferedtheotherpartyasaresultofsuchbreachordefault.16.5第三方权利限制划分TheThirdPartyshallnothaveanyrightsunderthisContractotherthanthoseexpresslyprovidedforinthisContract.ThepartiesshallnotberesponsibleforanyclaimsordemandsmadetheThirdParty.16.6第三方解除合同划分TheThirdPartymaynotterminatethisContractunlessthepartiesagreeinwritingtosuchtermination.ThepartiesshallnotbeliableforanycostsorexpensesincurredtheThirdPartyinconnectionwithsuchtermination.16.7第三方保险划分TheThirdPartyshallberesponsibleforobtainingandmaintainingallnecessaryinsurancecoverageinaccordancewiththetermsofthisContract.ThepartiesshallnotberesponsibleforanycostsorexpensesincurredtheThirdPartyinobtainingormaintainingsuchinsurancecoverage.16.8第三方合规划分TheaboveprovisionsshallapplytoanyThirdPartyinvolvedintheperformanceofthisContractandshallbebindingonthepartieshereto.第三部分：其他补充性说明和解释说明一：附件列表：1.合同主体资质证明2.设计与施工内容详细说明3.合同金额与支付方式详细说明4.设计与施工期限详细说明5.质量标准与要求详细说明6.技术与资料交换详细说明7.变更与调整详细说明8.保险责任详细说明9.合同生效、变更与终止详细说明10.保密条款详细说明11.环境影响与安全详细说明12.第三方介入详细说明13.附件清单（包括所有附件的名称和编号）14.违约行为及责任认定详细说明说明二：违约行为及责任认定：1.设