机场改造项目工程合同模板

机场改造项目工程合同模板第一篇范文：合同编号：[请填写具体的合同编号]

airporttransformationprojectconstructioncontracttemplate

甲方（以下简称“业主”）：

乙方（以下简称“承包商”）：

根据《中华人民共和国合同法》、《中华人民共和国建筑法》等法律法规，以及有关政策规定，经双方友好协商，本着平等、自愿、公平、诚信的原则，就甲方机场改造项目工程（以下简称“本项目”）达成一致，签订本合同。

第一条工程概况

1.1本项目位于[请填写项目具体地点]，主要包括[请填写项目主要包括的内容，如：跑道延长、航站楼扩建、机场配套设施建设等]。

1.2工程规模：[请填写工程规模，如：占地面积、建筑面积等]。

1.3工程总投资：[请填写工程总投资，单位：万元]。

第二条合同范围与内容

2.1乙方承担本项目的施工任务，包括但不限于：土建工程、安装工程、装饰工程、绿化工程、机场配套设施等。

2.2乙方应按照本项目的设计文件、技术规范和施工图纸进行施工，并保证工程质量、安全、进度和投资控制等目标顺利实现。

第三条合同价格与支付

3.1本项目的合同总金额为：[请填写合同总金额，单位：万元]。

3.2双方同意，合同价款采用以下支付方式：

（1）进度付款：按照工程进度，分期支付已完成工程量的70%；

（2）验收付款：工程验收合格后，支付剩余的30%。

3.3支付方式：银行转账。

第四条工期

4.1双方同意，本项目的施工期限为：[请填写施工期限，如：24个月]。

4.2乙方应按照约定的工期完成施工任务，如有延期，应承担相应的违约责任。

第五条质量与标准

5.1乙方应严格按照国家及行业标准进行施工，保证工程质量。

5.2工程质量应符合以下标准：

（1）设计文件要求；

（2）技术规范；

（3）施工图纸；

（4）国家及行业相关标准。

第六条安全生产与环保

6.1乙方应严格按照国家及行业安全生产规定，加强施工现场安全管理，确保施工安全。

6.2乙方应做好施工现场环境保护工作，遵守环保法规，确保施工过程中对环境的影响降到最低。

第七条违约责任

7.1双方应严格履行本合同各项条款，如一方违约，应承担违约责任，向守约方支付违约金，并赔偿因此给对方造成的损失。

7.2违约金计算方式为：违约金额×违约天数×1%。

第八条争议解决

8.1双方在履行本合同过程中发生的争议，应首先通过友好协商解决；如协商不成，任何一方均有权向项目所在地有管辖权的人民法院提起诉讼。

第九条合同的生效、变更与解除

9.1本合同自双方签字（或盖章）之日起生效，有效期至合同约定的工程竣工验收合格之日止。

9.2合同的变更或解除，应经双方协商一致，并签订书面协议。

9.3合同生效后，如遇国家政策调整、法律法规变化等不可抗力因素，双方可协商对本合同进行修改或补充。

第十条保密条款

10.1双方在签订和履行本合同过程中，应对对方商业秘密、技术秘密等保密信息予以保密，未经对方同意，不得向第三方披露。

10.2保密期限自本合同签订之日起计算，至合同约定的工程竣工验收合格之日止。

第十一条附加条款

11.1本合同未尽事宜，双方可签订补充协议，补充协议与本合同具有同等法律效力。

11.2本合同一式两份，甲乙双方各执一份，具有同等法律效力。

甲方（盖章）：______________

乙方（盖章）：______________

签订日期：[请填写签订日期]

第二篇范文：第三方主体+甲方权益主导

合同编号：[请填写具体的合同编号]

AirportTransformationProjectConstructionContractTemplate

ContractingPartyA(hereinafterreferredtoas"theOwner"):[PleasefillinthenameofthepartyA]

ContractingPartyB(hereinafterreferredtoas"theContractor"):[PleasefillinthenameofthepartyB]

ThirdParty(hereinafterreferredtoas"theConsultant"):[Pleasefillinthenameofthethirdparty]

Basedonthe"ContractLawofthePeople'sRepublicofChina","BuildingLawofthePeople'sRepublicofChina",andotherrelevantlawsandregulations,aswellastherelevantpolicyprovisions,thepartieshavenegotiatedingoodfaith,adheringtotheprinciplesofequality,voluntariness,fairness,andintegrity.Inordertoachievetheairporttransformationproject(hereinafterreferredtoas"theProject")inHubeiProvince,thepartieshavereachedthefollowingagreementsandhavesignedthiscontract.

Article1:ProjectOverview

1.1TheProjectislocatedin[Pleasefillinthespecificlocationoftheproject],mainlyincluding[Pleasefillinthemaincontentsoftheproject,suchas:runwayextension,terminalbuildingexpansion,airportsupportingfacilitiesconstruction,etc.].

1.2Thescaleoftheproject:[Pleasefillintheprojectscale,suchas:totalarea,buildingarea,etc.].

1.3Thetotalinvestmentoftheproject:[Pleasefillinthetotalinvestmentoftheproject,unit:tenthousandyuan(RMB)].

Article2:ContractScopeandContent

2.1TheContractorshallundertaketheconstructiontasksoftheProject,includingbutnotlimitedto:civilworks,installationworks,decorationworks,greeningworks,airportsupportingfacilities,etc.

2.2TheContractorshallcarryouttheconstructioninaccordancewiththedesigndocuments,technicalspecifications,andconstructiondrawingsoftheProject,andensuretherealizationofquality,safety,progress,andinvestmentcontrolgoals.

Article3:ContractPriceandPayment

3.1ThetotalcontractamountoftheProjectis[Pleasefillinthetotalcontractamount,unit:tenthousandyuan(RMB)].

3.2Thepartiesagreethatthecontractpriceshallbepaidinthefollowingmanner:

(1)Progresspayment:Pay70%ofthecompletedengineeringquantityaccordingtotheprojectprogress.

(2)Acceptancepayment:Paytheremaining30%aftertheprojectisacceptedandqualified.

3.3Paymentmethod:Banktransfer.

Article4:ConstructionPeriod

4.1ThepartiesagreethattheconstructionperiodoftheProjectshallbe[Pleasefillintheconstructionperiod,suchas:24months].

4.2TheContractorshallcompletetheconstructiontaskswithintheagreedperiod,andifthereisadelay,theContractorshallbearthecorrespondingbreachofcontractliability.

Article5:QualityandStandards

5.1TheContractorshallstrictlyfollownationalandindustrystandardsforconstructiontoensurethequalityoftheproject.

5.2Theprojectqualityshallmeetthefollowingstandards:

(1)Designrequirements;

(2)Technicalspecifications;

(3)Constructiondrawings;

(4)Nationalandindustry-relatedstandards.

Article6:安全生产andEnvironmentalProtection

6.1TheContractorshallstrictlycomplywithnationalandindustrysafetyproductionregulations,strengthenthesafetymanagementoftheconstructionsite,andensurethesafetyofconstruction.

6.2TheContractorshalldoagoodjobinenvironmentalprotectionattheconstructionsite,complywithenvironmentalprotectionregulations,andensurethattheimpactoftheconstructionprocessontheenvironmentisminimized.

Article7:BreachofContractLiability

7.1Thepartiesshallstrictlyperformallthetermsofthiscontract,andifanypartybreachesthecontract,itshallbearthebreachofcontractliability,paythebreachofcontractamounttotheinjuredparty,andcompensateforthelossescausedbythebreachofcontract.

7.2Thecalculationmethodoftheliquidateddamagesshallbe:Breachofcontractamount×Breachofcontractdays×1%.

Article8:DisputeResolution

8.1Anydisputesarisingbetweenthepartiesduringtheperformanceofthiscontractshallbefirstresolvedthroughfriendlyconsultation;iftheconsultationfails,eitherpartyhastherighttofilealawsuitwiththepeople'scourthavingjurisdictionovertheprojectlocation.

Article9:ContractEntryintoForce,Change,andTermination

9.1Thiscontractshalltakeeffectfromthedateofsignature(orseal)bybothpartiesandshallbevaliduntiltheprojectacceptanceiscompleted.

9.2Thechangeorterminationofthecontractshallbesubjecttotheconsentofbothpartiesandshallbeevidencedbyawrittenagreement.

9.3Ifthereareanychangesorsupplementstothiscontractduetotheadjustmentofnationalpolicies,changesinlawsandregulations,andotheruncontrollablefactors,thepartiesshallbeentitledtomodifyorsupplementthiscontract.

Article10:ConfidentialityClause

10.1Thepartiesshallkeepconfidentialthebusinesssecrets,technicalsecrets,andotherinformationoftheotherpartyduringthenegotiationandperformanceofthiscontract,andshallnotdisclosesuchinformationtoanythirdpartywithoutthepriorconsentoftheotherparty.

10.2Theconfidentialityperiodshallbecalculatedfromthesigningdateofthiscontracttotheacceptancedateoftheproject.

Article11:AdditionalProvisions

11.1Mattersnotprovidedforinthiscontractshallbesupplementedbysupplementaryagreements,whichshallhavethesamelegaleffectasthiscontract.

11.2Thiscontractshallbeexecutedintwocopies,oneforeachparty,bothofwhichshallhavethesamelegaleffect.

PartyA(seal):[PleasefillinthenameofPartyA]

PartyB(seal):[PleasefillinthenameofPartyB]

Dateofsigning:[Pleasefillinthedateofsigning]

Thethirdparty(theConsultant)isinvolvedintheprojecttoprovidetechnicalsupport,qualitysupervision,andacceptanceservices.TheConsultantisresponsibleforinspectingtheconstructionprogress,quality,safety,andenvironmentalprotectionmeasuresoftheProject,andhastherighttomakesuggestionsandrequirementstotheContractor.TheConsultantshallindependentlyperformitsdutiesandisnotresponsibleforthebreachofcontractbehavioroftheContractor.

Thepurposeofthethirdparty'sinterventionistoensurethequalityandsafetyoftheProject,andtopromotethesmoothprogressoftheProject.TheOwneristhemainbodyofthecontractandisresponsiblefortheoverallplanningandmanagementoftheProject.TherightsandinterestsoftheOwneraregivenpriority,andtherightsandobligationsoftheContractorarestrictlystipulatedtoprotectthelegalrightsandinterestsoftheOwner.TheinvolvementofthethirdpartyisconducivetotheeffectiveimplementationofthecontractandthesuccessfulcompletionoftheProject.

第三篇范文：第三方主体+甲方权益主导

合同编号：[请填写具体的合同编号]

BridgeConstructionProjectContractTemplate

ContractingPartyA(hereinafterreferredtoas"theOwner"):[PleasefillinthenameofthepartyA]

ContractingPartyB(hereinafterreferredtoas"theContractor"):[PleasefillinthenameofthepartyB]

ThirdParty(hereinafterreferredtoas"theConsultant"):[Pleasefillinthenameofthethirdparty]

Inaccordancewiththe"ContractLawofthePeople'sRepublicofChina","BuildingLawofthePeople'sRepublicofChina",andotherrelevantlawsandregulations,aswellastherelevantpolicyprovisions,thepartieshavenegotiatedingoodfaith,adheringtotheprinciplesofequality,voluntariness,fairness,andintegrity.Inordertoachievethebridgeconstructionproject(hereinafterreferredtoas"theProject")in[Pleasefillinthelocation],thepartieshavereachedthefollowingagreementsandhavesignedthiscontract.

Article1:ProjectOverview

1.1TheProjectislocatedin[Pleasefillinthespecificlocationoftheproject],mainlyincluding[Pleasefillinthemaincontentsoftheproject,suchas:bridgeconstruction,ancillaryfacilitiesconstruction,etc.].

1.2Thescaleoftheproject:[Pleasefillintheprojectscale,suchas:totallength,width,etc.].

1.3Thetotalinvestmentoftheproject:[Pleasefillinthetotalinvestmentoftheproject,unit:tenthousandyuan(RMB)].

Article2:ContractScopeandContent

2.1TheContractorshallundertaketheconstructiontasksoftheProject,includingbutnotlimitedto:bridgeconstruction,ancillaryfacilitiesconstruction,etc.

2.2TheContractorshallcarryouttheconstructioninaccordancewiththedesigndocuments,technicalspecifications,andconstructiondrawingsoftheProject,andensuretherealizationofquality,safety,progress,andinvestmentcontrolgoals.

Article3:ContractPriceandPayment

3.1ThetotalcontractamountoftheProjectis[Pleasefillinthetotalcontractamount,unit:tenthousandyuan(RMB)].

3.2Thepartiesagreethatthecontractpriceshallbepaidinthefollowingmanner:

(1)Progresspayment:Pay70%ofthecompletedengineeringquantityaccordingtotheprojectprogress.

(2)Acceptancepayment:Paytheremaining30%aftertheprojectisacceptedandqualified.

3.3Paymentmethod:Banktransfer.

Article4:ConstructionPeriod

4.1ThepartiesagreethattheconstructionperiodoftheProjectshallbe[Pleasefillintheconstructionperiod,suchas:24months].

4.2TheContractorshallcompletetheconstructiontaskswithintheagreedperiod,andifthereisadelay,theContractorshallbearthecorrespondingbreachofcontractliability.

Article5:QualityandStandards

5.1TheContractorshallstrictlyfollownationalandindustrystandardsforconstructiontoensurethequalityoftheproject.

5.2Theprojectqualityshallmeetthefollowingstandards:

(1)Designrequirements;

(2)Technicalspecifications;

(3)Constructiondrawings;

(4)Nationalandindustry-relatedstandards.

Article6:违约责任andLimitation

6.1TheContractorshallstrictlycomplywiththetermsofthiscontract,andifitbreachesthecontract,itshallbearthebreachofcontractliabilityandcompensatetheinjuredpartyforthelossescausedbythebreachofcontract.

6.2TheOwnershallhavetherighttoterminatethecontractandclaimdamagesiftheContractorbreachesthecontract.

Article7:DisputeResolution

7.1Anydisputesarisingbetweenthepartiesduringtheperformanceofthiscontractshallbefirstresolvedthroughfriendlyconsultation;iftheconsultationfails,eitherpartyhastherighttofilealawsuitwiththepeople'scourthavingjurisdictionovertheprojectlocation.

Article8:ConfidentialityClause

8.1Thepartiesshallkeepconfidentialthebusinesssecrets,technicalsecrets,andotherinformationoftheotherpartyduringthenegotiationandperformanceofthiscontract,andshallnotdisclosesuchinformationtoanythirdpartywithoutthepriorconsentoftheotherparty.

8.2Theconfidentialityperiodshallbecalculatedfromthesigningdateofthiscontracttotheacceptancedateoftheproject.

Article9:AdditionalProvisions

9.1Mattersnotprovidedforinthiscontractshallbesupplementedbysupplementaryagreements,whichshallhavethesa