版权说明:本文档由用户提供并上传,收益归属内容提供方,若内容存在侵权,请进行举报或认领
文档简介
第
PAGE
页共
NUMPAGES
页
2024钢管承包合同
2024SteelPipeContractingContract
ContractNumber:_________
DateofContract:July28,2024
PlaceofContract:_________
PartyA(Contractor):_________
PartyB(Subcontractor):_________
Preamble:
Thiscontractingcontractismadeinaccordancewiththe"ConstructionLawofthePeople'sRepublicofChina"andotherrelevantlawsandregulations,todefinethescopeofwork,rights,andobligationsofPartyBinthesteelpipeconstructionprojectundertakenbyPartyA.
Article1:ProjectOverview
1.1Theprojectnameis:_______.
1.2Theprojectlocationis:_______.
1.3Thesteelpipeconstructionworkincludes:_______.
Article2:ContractDuration
2.1Thecommencementdateoftheprojectis:_______.
2.2Thecompletiondateoftheprojectis:_______.
Article3:ContractPriceandPaymentTerms
3.1ThetotalcontractpriceforthesteelpipeconstructionworkisRMB_______(inwords:_______).
3.2PartyAshallmakepaymentstoPartyBinthefollowingmanner:
Adepositof_______%ofthetotalcontractpriceuponsigningthiscontract.
_______%ofthetotalcontractpriceuponcompletionofspecificmilestones.
Theremainingbalanceuponsatisfactorycompletionandacceptanceofthework.
Article4:ObligationsofPartyA
4.1PartyAshallprovidePartyBwithnecessaryconstructiondocuments,includingbutnotlimitedtoconstructiondrawingsandtechnicalspecifications.
4.2PartyAshallensurethattheconstructionsiteisreadyandsafeforPartyBtocommencework.
4.3PartyAshallmaketimelypaymentsasperthecontractterms.
Article5:ObligationsofPartyB
5.1PartyBshallprovidequalifiedpersonnel,materials,andequipmentforthesteelpipeconstructionwork.
5.2PartyBshallcomplywithallsafetyandconstructionregulationsandstandards.
5.3PartyBshallcompletetheworkwithintheagreedtimeframeandtothequalitystandards.
Article6:QualityandWorkStandards
6.1Thesteelpipeconstructionworkmustmeetthequalitystandardsstipulatedbynationallawsandregulations.
6.2PartyBshallrectifyanydefectsidentifiedduringtheacceptanceprocessatnoadditionalcosttoPartyA.
Article7:SafetyandEnvironmentalProtection
7.1PartyBshallcomplywithallsafetyandenvironmentalprotectionregulationsduringconstruction.
7.2PartyBshalltakenecessarymeasurestopreventsafetyaccidentsandenvironmentalpollution.
Article8:ChangesandAdditions
8.1Anychangesoradditionstotheprojectmustbeagreeduponbybothpartiesanddocumentedinwriting.
8.2ThecostofchangesoradditionsshallbebornebyPartyA.
Article9:AcceptanceofWork
9.1PartyBshallsubmitanacceptanceapplicationtoPartyAuponcompletionofthesteelpipeconstructionwork.
9.2PartyAshallorganizeacceptancewithin_______daysafterreceivingtheapplication.
Article10:BreachofContract
10.1Ifeitherpartybreachesthecontract,thebreachingpartyshallbearthecorrespondinglegalresponsibilities.
10.2Thepartysufferinglossesduetothebreachshallhavetherighttoclaimcompensation.
Article11:ForceMajeure
11.1Neitherpartyshallberesponsibleforfailuretofulfillobligationsduetoforcemajeureevents.
11.2Theaffectedpartyshallpromptlynotifytheotherpartyandprovidenecessarydocumentation.
Article12:DisputeResolution
12.1Anydisputesarisingfromtheexecutionofthiscontractshallberesolvedthroughnegotiation.
12.2Ifnegotiationfails,eitherpartymaysubmitthedisputetothe_______ArbitrationCommissionforarbitration.
Article13:Confidentiality
13.1Bothpartiesshallkeepallproject-relatedinformationconfidentialandshallnotdiscloseittoanythirdpartywithoutthewrittenconsentoftheotherparty.
Article14:AmendmentsandSupplements
14.1Anyamendmentsorsupplementstothiscontractmustbemadeinwritingandsignedbybothparties.
Article15:EffectivenessoftheContract
15.1Thiscontractshallcomeintoeffectuponsignatureandsealbybothparties.
Article16:Other
16.1Othermattersnotcoveredinthiscontractshallberesolvedbybothpartiesthroughnegotiation.
SignatureofPartyA:_________
Name(iflegalperson):_________
AuthorizedRepresentative:_________
Seal(ifapplicable):_________
Date:_________
SignatureofPartyB:_________
Name(iflegalperson):_________
AuthorizedRepresentative:_________
Seal(ifapplicable):_________
Date:_________
(Endofthefirsthalfofthecontract)
Article17:Insurance
17.1PartyBshallsecureandmaintainallnecessaryinsurancesfortheproject,includingbutnotlimitedtoconstructionallrisksinsuranceandworkers'accidentinsurance.
Article18:Subcontracting
18.1PartyBmaysubcontractpartsoftheworkwiththepriorwrittenconsentofPartyA.
18.2PartyBremainsresponsiblefortheworkofanysubcontractorsandtheircompliancewiththetermsofthiscontract.
Article19:Assignment
19.1Neitherpartymayassignthiscontractoranyrightsorobligationshereunderwithoutthepriorwrittenconsentoftheotherparty.
Article20:Notices
20.1Allnotices,requests,andothercommunicationsshallbeinwritingandshallbedeemedgivenwhendeliveredpersonallyorsentbyregisteredmailtotheaddressessetforthinthiscontract.
Article21:GoverningLaw
21.1ThiscontractshallbegovernedbyandconstruedinaccordancewiththelawsofthePeople'sRepublicofChina.
Article22:EntireAgreement
22.1Thiscontract,includingallattachments,constitutestheentireagreementbetweenthepartiesandsupersedesallpriornegotiations,representations,andagreementsbetweentheparties.
Article23:Termination
23.1Eitherpartymayterminatethiscontractbywrittennoticeintheeventofamaterialbreachbytheotherparty,providedthatthebreachingpartyhasnotcuredthebreachwithinaspecifiedperiod.
Attachment
I.ListofAttachments:
Projectplananddetailedconstructiondrawings.
Technicalspecificationsandworkstandards.
Projectscheduleandmilestones.
Listofkeypersonnelandtheirqualifications.
Insurancepolicydetails.
Qualityassuranceandcontrolplan.
II.BreachofContractandDetermination:
Failuretocommenceorcompletetheprojectontime.
Failuretomeettheagreedqualitystandards.
Non-compliancewithsafetyandenvironmentalregulations.
Unauthorizeduseordisclosureofconfidentialinformation.
III.LegalTermsandDefinitions:
"Subcontracting"referstotheengagementofanotherentitytoperformspecifictasksunderthecontract,withtheconsentofPartyA.
"Assignment"referstothetransferofcontractualrightsandobligationstoathirdparty,whichrequiresPartyA'sconsent.
"Forcemajeure"referstounforeseeableeventsbeyondthecontrolofthepartiesthatpreventperformanceofthecontract.
IV.ProblemsEncounteredDuringExecutionandSolutions:
Delaysinprojectprogressduetounforeseencircumstancesshallbeaddressedbyrevisingtheprojectschedule.
QualityissuesshallberesolvedbyPartyBtakingimmediatecorrectiveactions.
Safetyincidentsshallbemitigatedbyfollowingtheemergencyresponseplanandconductingathoroughinvestigation.
V.AllApplicationScenarios:
Civilengineeringprojectsforcommercialandindustrialbuildings.
Infrastructureprojectsincludingroads,bridges,andtunnels.
Publicfacilitiessuchasschools,hospitals,andgovernmentbuildings.
Anyotherconstructionprojectsthatarecompliantwithrelevantlawsandregulations.
VI.WarrantyandPost-CompletionServices:
PartyBshallprovideawarrantyfortheworkperformedforaperiodof_______yearsfromthedateofcompletion.
PartyBshallprovidenecessarypost-completionservices,includingtrainingandmaintenance,asagreedupon.
VII.LiquidatedDamages:
Intheeventofadelayinprojectcompletion,PartyBshallpayliquidateddamagestoPartyAattherateof_______perdayofdelay.
The
温馨提示
- 1. 本站所有资源如无特殊说明,都需要本地电脑安装OFFICE2007和PDF阅读器。图纸软件为CAD,CAXA,PROE,UG,SolidWorks等.压缩文件请下载最新的WinRAR软件解压。
- 2. 本站的文档不包含任何第三方提供的附件图纸等,如果需要附件,请联系上传者。文件的所有权益归上传用户所有。
- 3. 本站RAR压缩包中若带图纸,网页内容里面会有图纸预览,若没有图纸预览就没有图纸。
- 4. 未经权益所有人同意不得将文件中的内容挪作商业或盈利用途。
- 5. 人人文库网仅提供信息存储空间,仅对用户上传内容的表现方式做保护处理,对用户上传分享的文档内容本身不做任何修改或编辑,并不能对任何下载内容负责。
- 6. 下载文件中如有侵权或不适当内容,请与我们联系,我们立即纠正。
- 7. 本站不保证下载资源的准确性、安全性和完整性, 同时也不承担用户因使用这些下载资源对自己和他人造成任何形式的伤害或损失。
最新文档
- 《语文知识体系》课件
- 二零二四年度水利工程混凝土供应合同3篇
- 二零二四年度研发成果转化协议5篇
- 民间借贷担保合同书2024年范本
- 房屋院落租赁合同
- 2024版个体工商户加盟协议书2篇
- 2024年度云计算服务与数据中心运营协议
- 基于二零二四年度市场分析的区域营销战略合同
- 合作研发项目协议书版
- 《诉说亲情故事》课件
- 河南开放大学法学本科《法律社会学》作业练习1-3+终考试题及答案
- 停车场硬化施工方案及管理措施
- 2024年国家焊工职业技能理论考试题库(含答案)
- 职业技能培训机构教学管理规范
- 2024年小学体育新课标测评考试题库(含答案)
- 部编 2024版历史七年级上册期末(全册)复习卷(后附答案及解析)
- GB 15740-2024汽车防盗装置
- 《篮球移动技术 行进间传球》教案(共三篇)
- 眼镜验光员(二级)技能鉴定考试题及答案
- 期中试卷(1-5单元)(试题)-2024-2025学年五年级上册数学苏教版
- 人工智能岗位招聘笔试题及解答(某大型央企)2025年
评论
0/150
提交评论