




版权说明:本文档由用户提供并上传,收益归属内容提供方,若内容存在侵权,请进行举报或认领
文档简介
施工合同范例英文第一篇范文:合同编号:__________
ThisContractismadeandenteredintoonthis________dayof________,20_____,byandbetweenthefollowingparties:
PartyA:[NameofPartyA],acompanyorganizedandexistingunderthelawsof[Country/CountryofIncorporation],withitsprincipalplaceofbusinessat[AddressofPartyA],representedby[NameofAuthorizedRepresentative],hereinafterreferredtoas"Contractor".
PartyB:[NameofPartyB],anindividualorentityorganizedandexistingunderthelawsof[Country/CountryofIncorporation],withitsprincipalplaceofbusinessat[AddressofPartyB],representedby[NameofAuthorizedRepresentative],hereinafterreferredtoas"Owner".
WHEREAS,PartyAisengagedinthebusinessofconstructionandhasagreedtoundertaketheconstructionoftheProjectdescribedinthisContract,and
WHEREAS,PartyBisinterestedinhavingtheProjectconstructedbyPartyA,and
NOW,THEREFORE,inconsiderationofthemutualcovenantsandagreementscontainedherein,thepartiesagreeasfollows:
1.**ScopeofWork**
TheContractorshallperformallworknecessarytoconstructtheProjectdescribedintheattachedExhibitA(hereinafterreferredtoas"theProject"),inaccordancewiththeplans,specifications,anddrawingsprovidedbyPartyBoritsrepresentatives,andtheprovisionsofthisContract.
2.**ProjectDescription**
TheProjectshallconsistofthefollowing:
(a)Constructionofbuildings,structures,andfacilities;
(b)Installationofequipmentandsystems;
(c)Completionofallnecessarysitepreparationandcleanup;
(d)Compliancewithallapplicablelaws,codes,andregulations.
3.**ContractPrice**
ThetotalcontractpricefortheProjectshallbe[Amount],payableinaccordancewiththepaymentschedulesetforthinSection6below.
4.**PaymentTerms**
(a)TheOwnershallpaytheContractorinaccordancewiththefollowingschedule:
(i)[Percentage]ofthetotalcontractpriceupontheexecutionofthisContract;
(ii)[Percentage]ofthetotalcontractpriceupontheissuanceofthefirstprogresspaymentapplication;
(iii)[Percentage]ofthetotalcontractpriceupontheissuanceofthesecondprogresspaymentapplication;
(iv)[Percentage]ofthetotalcontractpriceupontheissuanceofthethirdprogresspaymentapplication;
(v)TheremainingbalanceuponcompletionandacceptanceoftheProjectbyPartyB.
(b)TheContractorshallsubmitaprogresspaymentapplicationtoPartyBupontheoccurrenceofeachmilestoneeventasspecifiedinthepaymentschedule.
5.**PerformanceSchedule**
TheContractorshallcompletetheProjectwithin[NumberofDays]daysfromthedateoftheNoticetoProceed,providedthattheProjectisfreefromdelayscausedbyPartyBorbyanyothercausebeyondthereasonablecontroloftheContractor.
6.**DelaysandLiquidatedDamages**
(a)IntheeventofanydelayinthecompletionoftheProject,theContractorshallbeliabletoPartyBforliquidateddamagesintheamountof[Amount]perdayforeachdayofdelay.
(b)PartyBshallhavetherighttoterminatethisContractupontheoccurrenceofanydelaythatcausestheProjecttobedelayedbeyondthemaximumdurationsetforthinthepaymentschedule.
7.**Warranties**
TheContractorwarrantsthattheworkperformedunderthisContractshallbedoneinagoodandworkmanlikemanner,inaccordancewiththeplans,specifications,anddrawings,andincompliancewithallapplicablelaws,codes,andregulations.
8.**Insurance**
TheContractorshallmaintain,duringthetermofthisContract,allnecessaryinsurancepoliciescoveringtheProject,including,butnotlimitedto,generalliabilityinsurance,workers'compensationinsurance,andpropertyinsurance.
9.**Indemnification**
TheContractorshallindemnify,defend,andholdharmlessPartyB,itsofficers,directors,employees,andagentsfromandagainstanyandallclaims,actions,demands,liabilities,costs,andexpensesarisingoutoforresultingfromtheContractor'sperformanceunderthisContractoranyactoromissionoftheContractor.
10.**Termination**
(a)ThisContractmaybeterminatedbyeitherpartyupontheoccurrenceofamaterialbreachoftheContractbytheotherparty,providedthatthenon-breachingpartygivesthebreachingpartywrittennoticeofthebreachandanopportunitytocurethebreachwithin[NumberofDays]days.
(b)UponterminationofthisContract,theContractorshallimmediatelyceaseallworkontheProjectandshallnotbeentitledtoanypaymentforworkperformedafterthedateoftermination.
11.**GeneralProvisions**
(a)ThisContractconstitutestheentireagreementbetweenthepartiesandsupersedesallprioragreements,negotiations,andunderstandings,whetherwrittenororal,relatingtothesubjectmatterofthisContract.
(b)ThisContractmaynotbeamendedormodifiedexceptbyawritteninstrumentexecutedbybothparties.
(c)IfanyprovisionofthisContractisfoundtobeinvalidorunenforceable,theremainingprovisionsshallremaininfullforceandeffect.
(d)ThisContractshallbegovernedbyandconstruedinaccordancewiththelawsofthe[Jurisdiction],withoutgivingeffecttoanychoiceoflaworconflictoflawprinciples.
(e)AlldisputesarisingoutoforrelatingtothisContractshallberesolvedbyarbitrationinaccordancewiththerulesofthe[ArbitrationInstitution].
(f)TheheadingsinthisContractareforconvenienceonlyandshallnotbeusedtointerpretorconstruethetermsofthisContract.
INWITNESSWHEREOF,thepartieshaveexecutedthisContractasofthedatefirstabovewritten.
ATTACHMENTS:
1.ExhibitA:ProjectDescriptionandScopeofWork
2.ExhibitB:Plans,Specifications,andDrawings
3.ExhibitC:InsuranceRequirements
4.ExhibitD:PaymentSchedule
第二篇范文:第三方主体+甲方权益主导
ThisContractismadeandenteredintoonthis________dayof________,20_____,byandbetweenthefollowingparties:
PartyA:[NameofPartyA],anentityorganizedandexistingunderthelawsof[Country/CountryofIncorporation],withitsprincipalplaceofbusinessat[AddressofPartyA],representedby[NameofAuthorizedRepresentative],hereinafterreferredtoas"Owner".
PartyB:[NameofPartyB],aconstructioncompanyorganizedandexistingunderthelawsof[Country/CountryofIncorporation],withitsprincipalplaceofbusinessat[AddressofPartyB],representedby[NameofAuthorizedRepresentative],hereinafterreferredtoas"Contractor".
PartyC:[NameofPartyC],aconsultingfirmspecializinginconstructionmanagement,withitsprincipalplaceofbusinessat[AddressofPartyC],representedby[NameofAuthorizedRepresentative],hereinafterreferredtoas"Consultant".
WHEREAS,PartyAdesirestohavetheProjectconstructedbyPartyB,and
WHEREAS,PartyChasbeenengagedbyPartyAtoprovideconstructionmanagementservicesfortheProject,and
NOW,THEREFORE,inconsiderationofthemutualcovenantsandagreementscontainedherein,thepartiesagreeasfollows:
1.**ScopeofWork**
PartyBshallperformallconstructionworknecessarytocompletetheProjectinaccordancewiththeplans,specifications,anddrawingsprovidedbyPartyA,underthesupervisionanddirectionofPartyC.
2.**Consultant'sRole**
PartyCshallactastheConstructionManagerfortheProject,providingthefollowingservices:
(a)ReviewingandapprovingtheContractor'sworkandprogress;
(b)Monitoringthequality,schedule,andcostoftheProject;
(c)CoordinatingwithallpartiesinvolvedintheProject;
(d)Ensuringcompliancewithalllaws,codes,andregulations.
3.**ContractPrice**
ThetotalcontractpricefortheProjectshallbe[Amount],payableinaccordancewiththepaymentschedulesetforthinSection6below.
4.**PaymentTerms**
(a)TheOwnershallpaytheContractorinaccordancewiththefollowingschedule:
(i)[Percentage]ofthetotalcontractpriceupontheexecutionofthisContract;
(ii)[Percentage]ofthetotalcontractpriceupontheissuanceofthefirstprogresspaymentapplication;
(iii)[Percentage]ofthetotalcontractpriceupontheissuanceofthesecondprogresspaymentapplication;
(iv)[Percentage]ofthetotalcontractpriceupontheissuanceofthethirdprogresspaymentapplication;
(v)TheremainingbalanceuponcompletionandacceptanceoftheProjectbyPartyA.
(b)TheContractorshallsubmitaprogresspaymentapplicationtoPartyAupontheoccurrenceofeachmilestoneeventasspecifiedinthepaymentschedule.
5.**PerformanceSchedule**
TheContractorshallcompletetheProjectwithin[NumberofDays]daysfromthedateoftheNoticetoProceed,providedthattheProjectisfreefromdelayscausedbyPartyAorbyanyothercausebeyondthereasonablecontroloftheContractor.
6.**DelaysandLiquidatedDamages**
(a)IntheeventofanydelayinthecompletionoftheProject,theContractorshallbeliabletoPartyAforliquidateddamagesintheamountof[Amount]perdayforeachdayofdelay.
(b)PartyAshallhavetherighttoterminatethisContractupontheoccurrenceofanydelaythatcausestheProjecttobedelayedbeyondthemaximumdurationsetforthinthepaymentschedule.
7.**Consultant'sResponsibilities**
(a)PartyCshallensurethattheContractor'sworkmeetsthespecificationsandstandardsrequiredbyPartyA.
(b)PartyCshallreportanydeviationsfromtheplansorspecificationstoPartyAimmediately.
(c)PartyCshallhavetheauthoritytomakedecisionsregardingtheProject,subjecttotheapprovalofPartyA.
8.**Owner'sRights**
(a)PartyAshallhavetherighttoapproveordisapproveanychangeorderssubmittedbyPartyB.
(b)PartyAshallhavetherighttorequestinformationandreportsfromPartyCatanytime.
(c)PartyAshallhavetherighttoterminatePartyBorPartyCforcause,uponwrittennotice.
9.**Owner'sObligations**
(a)PartyAshallprovidePartyBwithallnecessaryinformationandaccesstotheProjectsite.
(b)PartyAshallmaketimelypaymentstoPartyBandPartyCinaccordancewiththepaymentschedule.
(c)PartyAshallcooperatewithPartyCinthesupervisionandmanagementoftheProject.
10.**Contractor'sandConsultant'sObligations**
(a)PartyBshallperformtheworkinaskilledandworkmanlikemanner,inaccordancewiththeplans,specifications,anddrawings.
(b)PartyCshallactdiligentlyandingoodfaithintheperformanceofitsdutiesastheConstructionManager.
11.**ConsequencesofDefault**
(a)IntheeventofabreachofthisContractbyPartyBorPartyC,thenon-breachingpartyshallhavetherighttoterminatethisContractandseekdamages.
(b)PartyAshallnotbeliableforanydelayorfailuretoperformitsobligationsunderthisContractduetocircumstancesbeyonditsreasonablecontrol.
12.**GeneralProvisions**
(a)ThisContractconstitutestheentireagreementbetweenthepartiesandsupersedesallprioragreements,negotiations,andunderstandings,whetherwrittenororal.
(b)ThisContractmaynotbeamendedormodifiedexceptbyawritteninstrumentexecutedbyallparties.
(c)ThisContractshallbegovernedbyandconstruedinaccordancewiththelawsofthe[Jurisdiction],withoutgivingeffecttoanychoiceoflaworconflictoflawprinciples.
(d)AlldisputesarisingoutoforrelatingtothisContractshallberesolvedbyarbitrationinaccordancewiththerulesofthe[ArbitrationInstitution].
ATTACHMENTS:
1.ExhibitA:ProjectDescriptionandScopeofWork
2.ExhibitB:Plans,Specifications,andDrawings
3.ExhibitC:InsuranceRequirements
4.ExhibitD:PaymentSchedule
**SUMMARYOFTHIRDPARTYINTERVENTIONANDOWNER-DRIVENAPPROACH:**
TheinclusionofPartyCastheConsultantinthisContractservestoenhancetheoversightandmanagementoftheProject.PartyC'sroleastheConstructionManagerprovidesPartyAwiththefollowingbenefitsandprotections:
-Enhancedprojectcontrolandmanagementthroughadedicatedexpertinconstructionmanagement.
-Earlydetectionandresolutionofanypotentialissuesordeviationsfromtheplansorspecifications.
-Streamlinedcommunicationandcoordinationamongallpartiesinvolved.
-Assuranceofcompliancewithallapplicablelaws,codes,andregulations.
Theowner-drivenapproachensuresthatPartyA'sinterestsandobjectivesareprioritizedthroughouttheContract.Keyaspectsofthisapproachinclude:
-ClearandcomprehensivepaymenttermsthatprotectPartyA'sfinancialinterests.
-StrongterminationclausesthatallowPartyAtoterminatetheContractintheeventofabreachbyPartyBorPartyC.
-RobustdisputeresolutionmechanismsthatfavorPartyAintheeventofanydisagreements.
-AfocusonthetimelycompletionoftheProjectwithinthespecifiedschedule.
第三篇范文:第三方主体+乙方权益主导
ThisContractismadeandenteredintoonthis________dayof________,20_____,byandbetweenthefollowingparties:
PartyA:[NameofPartyA],anentityorganizedandexistingunderthelawsof[Country/CountryofIncorporation],withitsprincipalplaceofbusinessat[AddressofPartyA],representedby[NameofAuthorizedRepresentative],hereinafterreferredtoas"Owner".
PartyB:[NameofPartyB],ageneralcontractorwithexpertiseincommercialrealestatedevelopment,organizedandexistingunderthelawsof[Country/CountryofIncorporation],withitsprincipalplaceofbusinessat[AddressofPartyB],representedby[NameofAuthorizedRepresentative],hereinafterreferredtoas"Contractor".
PartyC:[NameofPartyC],aprojectmanagementfirmspecializinginrealestatedevelopment,withitsprincipalplaceofbusinessat[AddressofPartyC],representedby[NameofAuthorizedRepresentative],hereinafterreferredtoas"ProjectManager".
WHEREAS,PartyAdesirestodevelopacommercialrealestateprojectandhasengagedPartyBtoserveasthegeneralcontractorfortheconstructionphaseoftheproject,and
WHEREAS,PartyAhasalsoengagedPartyCtoactastheProjectManagertooverseetheoverallproject,and
NOW,THEREFORE,inconsiderationofthemutualcovenantsandagreementscontainedherein,thepartiesagreeasfollows:
1.**ScopeofWork**
PartyBshallperformallconstructionworknecessarytocompletetheProjectasdescribedintheattachedExhibitA,inaccordancewiththeplans,specifications,anddrawingsprovidedbyPartyA,underthesupervisionofPartyC.
2.**ProjectManager'sRole**
PartyCshallactastheProjectManagerfortheProject,providingthefollowingservices:
(a)Overseeingtheplanning,execution,andcompletionoftheProject;
(b)CoordinatingallaspectsoftheProject,includingdesign,construction,andsubcontracting;
(c)Managingthebudget,schedule,andqualityoftheProject;
(d)Ensuringcompliancewithallapplicablelaws,codes,andregulations.
3.**Contractor'sRights**
(a)PartyBshallhavetherighttoreceivepaymentsinaccordancewiththepaymentschedulesetforthinSection6.
(b)PartyBshallhavetherighttorequestchangestothescopeofworkortheprojectschedule,subjecttotheapprovalofPartyAandPartyC.
(c)PartyBshallhavetherighttoterminatethisContractforcauseuponwrittennoticetoPartyAandPartyC.
4.**ProjectManager'sRights**
(a)PartyCshallhavetherighttoapproveorrejectanychangestotheplans,specifications,orconstructionmethodsproposedbyPartyB.
(b)PartyCshallhavetherighttorequestadditionalinformationordocumentationfromPartyBasnecessarytoperformitsdutieseffectively.
(c)PartyCshallhavetherighttorecommendsubcontractorsorconsultantstoPartyAforapproval.
5.**PaymentTerms**
(a)TheOwnershallpaytheContractorinaccordancewiththefollowingschedule:
(i)[Percentage]ofthetotalcontractpriceupontheexecutionofthisContract;
(ii)[Percentage]ofthetotalcontractpriceupontheissuanceofthefirstprogresspaymentapplication;
(iii)[Percentage]ofthetotalcontractpriceupontheissuanceofthesecondprogresspaymentapplication;
(iv)[Percentage]ofthetotalcontractpriceupontheissuanceofthethirdprogresspaymentapplication;
(v)TheremainingbalanceuponcompletionandacceptanceoftheProjectbyPartyA.
6.**PerformanceSchedule**
TheContractorshallcompletetheProjectwithin[NumberofDays]daysfromthedateoftheNoticetoProceed,providedthattheProjectisfreefromdelayscausedbyPartyAorbyanyothercausebeyondthereasonablecontroloftheContractor.
7.**DelaysandLiquidatedDamages**
(a)IntheeventofanydelayinthecompletionoftheProject,PartyBshallbeliabletoPartyAforliquidateddamagesintheamountof[Amount]perdayforeachdayofdelay,unlesssuchdelayiscausedbyPartyAorbycircumstancesbeyondthereasonablecontrolofPartyB.
(b)PartyAshallhavetherighttoterminatethisContractupontheoccurrenceofanydelaythatcausestheProjecttobedelayedbeyondthemaximumdurationsetforthinthepaymentschedule.
8.**Contractor'sObligations**
(a)PartyBshallperformtheworkinaskilledandworkmanlikemanner,inaccordancewiththeplans,specifications,anddrawings.
(b)PartyBshallprovidePartyCwithregularprogressreportsandupdatesonthestatusoftheProject.
9.**ProjectManager'sObligations**
(a)PartyCshallactastheprimarypointofcontactforPartyBandshallfacilitatecommunicationbetweenallpartiesinvolvedintheProject.
(b)PartyCshallensurethattheProjectiscompletedinatimelyandcost-effectivemanner.
10.**Owner'sObligations**
(a)PartyAshallprovidePartyBwithallnecessaryinformationandaccesstotheProjectsite.
(b)PartyAshallmaketimelypaymentstoPartyBandPartyCinaccordancewiththepaymentschedule.
(c)PartyAshallcooperatewithPartyCinthesupervisionandmanagementoftheProject.
11.**Owner'sLimitations**
(a)PartyAshallnotunreasonablywithholdapprovalforchangesormodificationstotheProject.
(b)PartyAshallnotinterferewiththeContractor'soperationsortheProjectManager'smanagementwithoutjustcause.
(c)PartyAshallnotbeliableforanydelayorfailuretoperformitsobligationsunderthisContractduetocircumstancesbeyonditsreasonablecontrol.
12.**GeneralProvisions**
(a)ThisContractconstitutestheentireagreementbetweenthepartiesandsupersedesallprioragreements,negotiations,andunderstandings,whethe
温馨提示
- 1. 本站所有资源如无特殊说明,都需要本地电脑安装OFFICE2007和PDF阅读器。图纸软件为CAD,CAXA,PROE,UG,SolidWorks等.压缩文件请下载最新的WinRAR软件解压。
- 2. 本站的文档不包含任何第三方提供的附件图纸等,如果需要附件,请联系上传者。文件的所有权益归上传用户所有。
- 3. 本站RAR压缩包中若带图纸,网页内容里面会有图纸预览,若没有图纸预览就没有图纸。
- 4. 未经权益所有人同意不得将文件中的内容挪作商业或盈利用途。
- 5. 人人文库网仅提供信息存储空间,仅对用户上传内容的表现方式做保护处理,对用户上传分享的文档内容本身不做任何修改或编辑,并不能对任何下载内容负责。
- 6. 下载文件中如有侵权或不适当内容,请与我们联系,我们立即纠正。
- 7. 本站不保证下载资源的准确性、安全性和完整性, 同时也不承担用户因使用这些下载资源对自己和他人造成任何形式的伤害或损失。
最新文档
- 《连锁经营管理理论与实务》课件第一章
- 《高等数学》上册课件09-01级数及其基本性质
- 2025年供应链管理与流程优化考试题及答案
- 新建月饼包装机项目可行性研究报告立项模板
- SMT错件问题及预防措施培训
- 2025年各类艺术类专业考试试卷及答案
- 2025年运动医学考试试题及答案分享
- 2025届福建省莆田一中学英语七下期末经典试题含答案
- 吉林省柳河县第三中学2025年英语七下期中复习检测试题含答案
- HR咖啡培训课程
- 腹股沟疝护理新进展
- 机修工2025年上半年工作总结范文
- 食品标准操作规程
- 《人民法院》课件
- 青海大学《普通化学》2022-2023学年第一学期期末试卷
- 《传感器与检测技术》全套教案
- 人力资源 公司劳务派遣招聘流程及制度
- 新版人音版小学音乐一年级下册全册教案
- 初中语文:非连续性文本阅读练习(含答案)
- 国开(山东)2024年《小学生心理健康教育》形考1-3终考答案
- 人工智能营销(第2版)课件全套 阳翼 第1-8章 迈入人工智能领域-人工智能营销的伦理与法律问题
评论
0/150
提交评论