买卖合同中英对照_第1页
买卖合同中英对照_第2页
买卖合同中英对照_第3页
已阅读5页,还剩6页未读 继续免费阅读

下载本文档

版权说明:本文档由用户提供并上传,收益归属内容提供方,若内容存在侵权,请进行举报或认领

文档简介

SALESCONTRACTContractNumber:AcceptaneeExpirationDate:ContractDate:SELLER:Companyname:Address:Signatory:Email:BUYER:Companyname:Address:Tel:Fax:Signatory:Email:OBJECTThe sellerherewithsellandtheBuyerherewithpurchaseinaccordaneewiththespecificationsandqualitydescribedinthiscontract(hereinaftercalled“Goods').ThespecificationofthegoodsprovidedinAppendixNo.2hereto.DELIVERYBASISANDTERMSTheSellershalldeliverthegoodsunderdeliveryofconditions:CIFdestinationinaccordaneewithINCOTERMS-2000.LoadingPort:ShallbedefinedintheDeliveryScheduleAppendix3,orasdesignatedbySeller.CountryofExport:AsperDeliveryScheduleAppendix3,orasdesignatedbySellerandCountryofImporttobedesignatedbytheBuyer.ThenamedPortsofdestination:for30(thirty)dayspriortothebeginningofshipmentofeachvessel,theBuyerwillinformtheSelleraboutport(ports)destinationifdifferent.TermsofDeliveryareincludedintheDeliveryScheduleinAppendixNo.3hereto.QUANTITYOFGOODSThe unitofmeasurementinthiscontractismetrictonsofweight(MTW).MonthsarecalendarmonthsaccordingtotheGregoriancalendar.Quantity ofeachshipmentisinMTVY+/-5%)asperDeliveryinAppendixThe totalquantityoftobedeliveredisshownintheDeliveryScheduleinAppendix3(+/-5%).The goodswillbedeliveredover12calendarmonthsinaccordaneewithDeliveryScheduleinAppendixNo.3hereto.The quantityofgoodswillbeconfirmedonacertificateissuedbytheindependentinternational surveycompany“SGS(SocieteGeneraldeSurveillanee), CIQorCCICatsellersexpense.Otherquantityinspectionsattheportofunloadingshallbeatthebuyersexpense.Weightforinvoicingpurposesshallbeestablishedbytheactualnetweight.Weightfranchiseof0.5%shallbeallowedagainstBillofLadingweight.Incaseshort/overweightexceeds+/-5%theSeller/BuyershallcompensateBuyer/Sellerfortheamountexcludingthefranchiseonthebasisofcontractedprice.QUALITYOFGOODSThe goodsshallconformtothespecifications inAppendixNo.2hereto.Thequalityofthegoodswillbe confirmedbyacertificateissued bytheindependentinternational surveycompany“SGS(SocieteGeneraldeSurveillanee)whichshallbebingingonbothpartiesinallrespects,includingbutnotlimitedtothereplacementoffaultygoodspaidforbytheseller.Otherqualityinspectionsattheportofunloadingshallbeatthebuyersexpense.PRICEANDTOTALAMOUNTOFCONTRACT5.1TheBuyershallpaytheSellerinUnitedStatesDollars“USD5.1TheBuyershallpaytheSellerinUnitedStatesDollars“USDThepriceofgoodsisasfollows:ISRI 200-206is$xxxUSDperMTWpriortounloadingat30,000MTWpermonthfor12months.The valueofdeliveriesis$xxxxxxUSD(+/-5%)(fivePercent)AmericanDollars.Thetotalamountofthecontractisabout$xxxxxxxxUSD(+/-5%)(FivePercent)AmericanDollars.ThepriceofgoodsincludesallcostsincurredbySelleruptoandincluding deliverybasisCIFatthedestination portexceptwherethecontractspecificallyprovidesforacosttobebornebytheBuyer,portdemurragecharges,tariffs,andexport/importfees.Theunitpriceisfixedandfirmforanyquantity notexceedingthemaximumpermittedunderthecontracteitherdeliveredorstored(ifvesselsaredelayedbythebuyersfailuretounloadinatimelymanner)onorbeforeexpireoftheperiodstatedinsub-clause6.1,orsuchextendedperiodasexpresslyprovidedinthiscontractoragreedbymutualwrittenunderstanding.Theprice includes upto30daysstorageandinsuraneeofanyconsignmentintheportofloading.DELIVERYTERMSANDPARTIESOBLIGATIONSThe Sellershalldeliverythetotalquantityofgoodswithin12monthsperiodinaccordancewiththeDeliverySchedule,AppendixNo.3hereto.TheSellershallstartthedeliveryofthefirstconsignmentinaccordaneewiththeProcedure&Terms,AppendixNo.1hereto.AllprovisionsincludedintheDeliverySchedulewillbeobservedbybothBuyerandSellerandbreachesintheprovisionswillbesubjecttopenaltiesasperprovisionsunderclauses11.0and12.0.ThePartiesmayagreeupontheextensionofthedeliveryperiod.Onthisevent,thePartyresponsible forthedelays(SellerindeliveryorBuyerinunloading)willhavetobeatthecostsfortheextensionofthevalidityoftheLetterofCreditaswellasthecostsofstorageinthePortofLoading.Should theBuyerdelaythevesselsforloadingaccordingtoprovisionsinthedeliveryscheduleoraspersub-clause8.3below,theSellerisentitled tostorethegoodsintheportwarehouseandgetaWarehouseReceipt(WR)touseascashingdocumentinsteadofBOL.DELIVERYACCEPTANCEOFGOODSUnder thecondition ofdeliveryCIF,theSellerandBuyerisobligatedtopaycharges,however,riskoflossordamageofthegoodsandanyadditionalchargesarisingafterthetransferofthegoodsoverthehand-railofavesselintheportofloadingshallpassfromSellertotheBuyeronlyifthebuyerisproviding supplementalinsuranee.Titlefor thegoodswillpassfromSellertotheBuyeruponclearaneeoffundsintotheSellersaccountbymeansofCleanOnBoardBlankEndorsedOceanBillofLadingmarked“Negotiable”andriskifsubjecttoclause7.1ThequalityandquantityofgoodsstatedintheBillofLoading,andorWRwherepermitted)shallbeconclusiveevideneeofthequalityandquantityofgoodsdelivered.Noclaim(s)againstqualityorquantityreceived30(thirty)daysfollowingreceiptofSGSqualityorquantityreportasappropriatewillbetakenintoconsiderationoractionable.PAYMENTTERMSANDCONDITIONS8.1 PaymentforeachconsignmentinfavoroftheSellerintheapproximate8.1 Paymentamountof$xxxxxxxUSDAmericanDollarsshallbeeffected100%atsightafterreceiptbytheadvisingbankofalldocumentsrequiredinclause9.0onlywithavalidityof12+3monthsincaseofdelays..TypeofBankinstrument aspaymentguarantee: anunconditional,confirmed,irrevocable,documentary,LetterofCreditwhichshallbeissuedbythebuyersbankdefinedasIstNationalBankofAnytowndirectlytotheSellersBankshowninAppendix6.IstNationalBankofAnytownshallissueinfavoroftheSeller1(one)LetterofCredit,inaccordaneewiththetermsprovidedinAppendixNo.1hereto.TheoperativeLetterofCreditwillbeissuedonorbeforeFebruary18,2005otherwiseabreechthereofwillbedeclaredandsubjecttodemandunderclause8.5.The BuyershallTTarefundabledeposittoaccompanythiseontract intheamountof$xxxxxxxxxUSD,whichshallberefundeduponreceiptofclearfundson

avalidLetterofCreditasperthiscontract.The nextoftheLetterofCreditisshowninAppendixNo.4hereto.ThefinaltexttobeprovidedbythebuyersbankshallbesubjecttoapprovalbytheSellerasaconditionofthebuyerscomplianeewiththepresentcontract.IntheeventthattheBuyerfailstoissuetheLetterofCreditincomplianeewithclause8.1,thenpaymentforthefullcontractvalueshallbemade100%atsightofdemanduponthebuyerwithoutprotestasacontractbreech.TheSellerwillsenddocumentsforeachconsignmenttotheBuyerbycourieroriginatingfromtheSellersofficeswithin21(twentyone)bankingdaysfromtheBillofLadingDate.FortheproperperformaneeofthecontractandcounterguaranteeoftheBuyersvalidLetterofCredit,SellershallissueaBankPerformanceBondintheamountofxxxxxxUSDAmericanDollarswithavalidityof12+3monthsincaseofdelays.ThePerformanceBondwillbetheactinginstrumentimmediatelyfromdateofreceptionofthefirstpaymentreceivedfromthebuyersbankwhentheSellersbankwillissueaSBLCnamingthebuyerasthebeneficiaryintheamountoftheperformancebond.Should theBuyerdelaythevesselforloadingoftheGoodsperdeliveryscheduleorsubmittednotification dateorwithin7(seven)calendardaysfollowingthescheduleddate,theSellerisentitledtostorethegoodsintheportattheBuyersexpenseandriskandreceiveaWarehouseReceipt(WR)thatcanbeusedinsteadoftheBillofLading.AllbankchargesrelatedtotheissuanceoftheLetterofCreditarefortheBuyersaccountandallthoserelatedtotheissuanceofthePerformanceBondareontheSellersAccount.BankchargesrelatedtothenegotiationofeitherdocumentarefortherespectiveBeneficiaryaccounts.Any extensionofthevalidityofeitherdocumentwillbebornebythesideinfaultfromtheirextension.Spelling andtypographicalerrorsanddifferencesofsuchnaturebetweenBankissuedandBeneficiaryissueddocumentsshallnotbedeemeddiscrepanciesprovidedthattheintentofthewriteisclearfromthecontextandinsuchcaseonlyUCP500regulationsshallapplyatanytime.DOCUMENTSREQUIREDFORPAYMENTThe Sellershallprovidewitheachconsignmentafullset(6/6)CleanonBoardOceanBillofLadingsignedbyanauthorizedrepresentativeofNetworkOceanlines,signedbytheMasterandshowingvesselsstampandshowing“CLEANONBOAF”,followingmastersremarkareacceptable:Wetbeforeshipment ;Loadedfromopenarea;Atmosphericallyrustywithin21(twenty-one)daysfromdateofpaymentCommercial invoiceissuedbyseller:6originals and6original copiesshowingContractNumber, descriptionofgoods,piecesofbundlesofgoods, unitprice,totalamount,gross/netweightsofthegoods.DOCUMENTNOTREQUIREDFORPAYMENT10.1QualitycertificateissuedbySGSintriplicate:showingthequalityand

10.1QualitycertificateissuedbySGSintriplicate:showingthequalityandallrequiredbychemicalstructureasshowninAppendixNo.2heretoofthegoodsaccordingtothepresentcontent:3originalsand3originalcopiesorifAQSIQ/CIQ/CCICisrequiredbytheBuyersthenSellershallarrangeallQualityinspectionsatSellersexpensefromAQSIQ/CIQ/CCICexcludingtheportofunloading.QuantityassayissuedbySGSintriplicate,showingthequantityofthegoodsloadedonboardvesselorifAQSIQ/CIQ/CCICisrequiredbytheBuyerthenSellershallarrangeallQuantityinspectionsatSellersexpensefromAQSIQ/CIQ/CCICexcludingtheportofunloading..Original certificateoforigin issuedbyChamberofCommerceandIndustryofthecountryofexport:3originalsand3originalcopies.Mastersnotice,showingdescr iptionofgoods,nameofvessel,B/LNo.Gross/Netweightsofthegoods,piecesorbundlesofgoods,timeofarrival,berthing,shippingagentatthedestinationifavailable,loadingtime,releasetime,signedbyMasterandport.AllofthedocumentsincludingtheB/L,invoice,parkinglist,originalcertificateandsoonhasbeenfaxedtothebuyerwithin7daysafterB/Ldate.XI.FORCEMAJEUREBothsidesinthiscontractwillbeexoneratedfromtheirobligationincaseofforcemajeureevent.Force majeureisunderstoodasperprovisionsunderICC500andmeansanyeventsuchasfive,explosions,hurricanes,floods,earthquakesandsimilarnaturalcalamities,wars,epidemics, militaryoperations,terrorism,riots,revolts,strikes,industrial unrest,governmentembargoes,orotherunforeseeable actionsoccurringaftertheconclusion ofthiscontractandoutsidethesidesreasonablecontrolandwhichcannotbeavoidedbythereasonablediligeneethatcoulddelayorpreventtheperformaneeofeithersidesobligationsinthiscontract.The partytothiscontractwhoseperformaneeofthiscontractispreventedbyaForceMajeureeventmusenotify theotherpartywithin7(seven)daysoftheeffectivedateofoccurrenee, whichnotice istobeconfirmedbyacertificateissuedbythelocalchamberofcommerceandIndustry,includingparticularsoftheeventandexpectedduration.FailuretosubmitsuchanotificationwillpreventthepartiesexonerationfromcontractualobligationsunderForceMajeureeventmakessuchnoticeimpossible.Theperformanceofeitherpartiesobligationswillbeinsuchcasepostponedwiththeperiodoftheexistence oftheForceMajeureeventplusareasonableperiodtoremobilizingproductionandshipping.Nopenaltyshallbepayableforthedurationofthisdelay.Should thedelaycausedbyaForceMajeureeventlastformorethan1(one)monththesideswillattempttoagreemeasurestoallowcontracttocontinue.Shouldsuchanagreementmotbereachedwithin30(thirty)daysfromthedateofcertifiedForceMajeureevent,thesidesareentitledtoterminatethecontract.TheForce MajeureeventdoesnotexoneratetheBuyer frompayingforthegoodsalreadydeliveredunderdocumentsinsection9BillofLading.XII.SELLERLIABILITY12.1GoodsshallbeconsideredinfullquantityifwithintoleranceXII.SELLERLIABILITY12.1Goodsshallbeconsideredinfullquantityifwithintoleranceshallprovided undersub-clause3.1andasperdeliveryschedule.“DateofdeliveryshallbethedateontheBillofLading.If Sellerfailstodeliveryfullquantityorquality ofanyconsignment,onlywiththeconfirmationfromthebuyer,hehastherighttomakeitcompletewiththenexttwoconsignments.Failure todeliveryfull quantity within extendedperiodwill entailpenaltiesattherateof0.3%(pointthreepercent)proratatemporizeofthevalueofforliquidateddamages.theundeliveredgoods.Thetotalvalueofthepenaltiescannotexceed5%(fivepercent)theundeliveredgoods.Thetotalvalueofthepenaltiescannotexceed5%(fivepercent)ofthevalueoftheundeliveredgoodsatwhichtimefullbreechifdeclaredautomatically.ofthevalueoftheundeliveredgoodsatwhichtimefullbreechifdeclaredautomatically.12.4ShouldtheBuyerdecide,atanytimeduringthemonthlyperiodofdelivery,totakeonlyapartialdeliveryrather thanwaitforthefullquantity(ifthequantityisnotalreadyavailableinportandreadyforloading)thentheSellerwillnotbeliable12.4ShouldtheBuyerdecide,atanytimeduringthemonthlyperiodofdelivery,totakeonlyapartialdeliveryrather thanwaitforthefullquantity(ifthequantityisnotalreadyavailableinportandreadyforloading)thentheSellerwillnotbeliableAnysumsforwhichtheSellerareliableaspenaltiesforwhichnoprovisionaremadeinthiscontractaremadeinthePerformaneeBondaremadeagainstinvoiceissuedbythedamagedsideandbybanktransferwithinmaximum10(ten)bankingdaysasformthesubmittedinvoicedate.BUYERLIABILITYAnysumswhichtheBuyerareliableaspenaltiesforwhichnoprovisionsaremadeinthiscontractaremadeagainstinvoiceissuedbySellerandbybanktransferwithinmaximum10(ten)bankingdaysasforthesubmittedinvoicedate.“ScheduleddateofArrival”meansdatewhenthevesselshouldbealongsidequayandavailabletotakedeliveryoftheGoodsasperbothSellerandBuyermutualnotificationsandprovisionsinAppendixNo.3hereto.Should thevesselnotarrivewithin15(fifteen) calendardaysasfromscheduled/notified dateasaresultofdelaysbythebuyerattheunloadport,theBuyerwillpaytheSellerpenaltiesatthedailyrateof0.3%(pointthreepercent)proratetemporizeofthevalueofundelivered goodsbutthetotalamountshouldnotexceed5%(fivepercent)oftheirvalue.Should thevesselnotarriveforloadingwithin beforestatedperiodasaresultofthebuyerattheunloadport,andthegoodsbestoredintheportWarehousetheBuyerwillberesponsibleforthepaymenttotheportauthoritiesatthefollowingratesperdayoverthepermitted30days:13.4(a) 31-60days$0.30USD/day/MTW13.4(b) 61-75days$0.40USD/day/MTW13.4(c)76-90days$0.50USD/day/MTW13.4(d)Over90daysisnotallowedtokeepthegoodsandtheportisentitledtosellthegoodstocoverlosses.ThesedetailsaretobesettledbetweentheBuyerandthePortAuthorities.The paymentsofthestoragecostsinporthavenoconnectionwiththepaymentpenalties,whicharepaidseparatelytotheSeller.To makepaymentintargetdatesforeachconsignmentshallbeeffectedbywithin3(three)bankingdaysafterreceiptbytheadvisingbankofalldocumentsrequiredunderclause9.

The BuyerundertakesandguaranteesthattheLetterofCreditwithin5(five)bankingdayswillsendtoSellerconfirmationaboutissuaneeofLetterofCreditunderthetermsofthiscontractinthefavoroftheSeller.LAWANDARBITRATONofCredit.14.1observed14.2ThecontractissubjecttoUnitedStatesLaw,ICCrulesaretobeandUCCLawwillsupercedeoverICCifinconflict.amicably.EitherunderexistingTheCIGSguidelinesSellerandBuyerwilltrytosettlealldisputespartydaysthismayservenoticeaftersuchnoticecontract uniessontheotherrequiringand,ifnotsettledtobreechofpaymentoccursanydisputetobesettledreferittoarbitration14.1observed14.2ThecontractissubjecttoUnitedStatesLaw,ICCrulesaretobeandUCCLawwillsupercedeoverICCifinconflict.amicably.EitherunderexistingTheCIGSguidelinesSellerandBuyerwilltrytosettlealldisputespartydaysthismayservenoticeaftersuchnoticecontract uniessontheotherrequiringand,ifnotsettledtobreechofpaymentoccursanydisputetobesettledreferittoarbitrationbythebuyerorfailurewithin30(thirty)inaccordaneewithtoposttheLetterThearbitrationwillbeheardbyoneormorearbitratorsappointedmutualagreementofthepartiesandinaccordaneewiththeRulesandtheArbitrationAct1996.TheseatofarbitrationshallbeUnitedStatesofAmerica.Theawardshallbeenforceableinanycountry,andaLetterRogatoryshallbedeemedacceptedwithoutcontestorprotest.Should paymentnotbereceivedwhenscheduledunderthiscontractandSellerdeclarebreechofcontractthenSummaryJudgmentundertheLawsoftheUnitedStateofAmericashallapplyandbedeemedautomaticforthefullcontractvalueanddamagesclaimedtherein underUCClawwiththeauthoritythereintorecoverthosecostsinanycountry.CONTRACTTERMINATIONEither partymayterminatethecontractshouldtheothersiderefuseperformaneeofasubstantivecontractualobligationunlesstheLCisnotpostedbythebuyer,butexcludingrefusalcausebyaForceMajeureevent.Notificationofterminationistooccurwithin30(thirty)calendardaysfollowingnon-performaneeifcontractualobligations.Noterminationispermittedshouldanyofthesideexcusetheirobligations withinthestated30(thirty)daysfromthenotification date.ASSIGNMENTAny ofthesidesisallowedtoassigntheeontractorpaymentinstrumentinordertosecuretheperformaneeofitsobligations.Any assigneeorlegalsuccessortorather partyshallassumeallobligationsandbenefitsofthecontract.AssignmentispermittedundermandateissuedbytheSeller.GENERALPROVISIONSAmendmentstothepresenteontractshallbevalidonlyifagreedinwritingandsignedbydulyauthorizedrepresentativesofbothsides.Correspondenceinthecourseoftheordinaryadministrationoftheeontractsuchasbutnotlimitedtonotification ofanticipateddeliverydatesmightbesentbyfax,anyelectronicmeansormail.Noticesofsuspension,terminationortoinvokearbitrationshallbesentasanadvaneefaxwithanoriginalbycourierserviceandshallbedeemeddeliveredontheevideneeddateofthefacsimile.The Ianguageofthecontractandthecorrespondence,notices,certificates,BillsofLadingshallbeEnglish.The contract comprisesthepresentdocuments,AppendicesandAddendums.Thiscontractsupercedesallpriornegotiations,representationsandagreementsanditisthesoleagreementbetweenthesidesforthesaleandpurchaseofthegoods.The liabilitytowardstheotherpartyislimitedtopenalties,charges,damagesandremediedexpresslystatedinthislossarisingunderthelawofcontractortortincludingnegligeneeandbreechofduty.ThebuyeracknowledgesthattheSellerisanAmericanCorporationwhohascollateralbusinessagreementswithothercountriesintheperformaneeofthiscontractincluding,thequantityandqualityoftherateofdeliveryofgoods,theshipmentmethodsdeployedintheperformaneeofthecontract,thefinancialexchangeofthetermswithinthecontractandsubjecttothelawsofthosecountriesatalltimes.ThebuyeracknowledgesthatcommissionsarepaidinsupportofthiscontractandarepaidbytheSellerunlessthebuyerbreechesthiscontractthencommissionsshallbepaidbythebuyerbaseduponthetotalcontractvalue.Anycommissions,fees.OrothersuchchargesabovethisamountaretheresponsibilityoftheBuyerorunlesswaivedbytheBuyertoallowtheSellertobethepaymasterforsuchfees.XVIII.EFFECTIVEDATEThis contractshallcomeintoeffectwhentheBuyerandSellerhavebothinitialedandsignedthepresentdocumentanditsappendices.XIX.CONFIDENTIALITYAGREEMENTSeller andBuyershalltreatinformationprovidedbytheotherpartyonastrictlyprivateandconfidential basis.SellerandBuyershalltakeallnecessarystepstopreventtheothersconfidentialinformationfrombeingmisusedordisclosedormadepublictoanythirdpartyexceptasneededtosuccessfullycompletetheContractortoavoidconflictingclaims(andexceptasmayberequiredinaccordaneewiththeapplicablelaw).Buyer shallnotusetheconfidential information providedtheSellerinsuchawayasto:19.2(a)CircumventtheSellerinthecommercialdealingswithanyandallsuppliersunderthecontract,or19.2(b) KnowinglydoanythingtocausetheSellertoloseanyfeesorcommissionsthataredueormaybecomedueundertheSelleragreementwiththesuppliersundertheContract,ifany,orSeller shallnotusetheconfidential information providedbyBuyerinsuchawayasto:19.3(a)CircumventBuyerinthecommercialdealingswiththeConsigneeifintroducedbytheBuyer,or19.3(b) KnowinglydoanythingtocauseBuyertoloseanyfeesorcommissionsifdueormaybecomedueunderthepresentContractandadditionalappendices,or19.3(c)DoanythingtocircumventBuyerinsuchawayastoputBuyeratacommercialdisadvantagewithaconsigneeifexisting,SellerandBuyershallkeepeachotherfullyinformedabouttheprogressofallcurrentandfuturecontractnegotiationsandabouttheperformaneeofthecontract.The obligation ofconfidentiality oftheSellersandBuyershallremaininforceforaperiodof5(five)yearsfromthedatehereof.Anybreachoftheseprovisionswillentailpaymentofdamagestotheotherparty.XX.NON-CIRCUMVENTIONAGREEMENTThepar

温馨提示

  • 1. 本站所有资源如无特殊说明,都需要本地电脑安装OFFICE2007和PDF阅读器。图纸软件为CAD,CAXA,PROE,UG,SolidWorks等.压缩文件请下载最新的WinRAR软件解压。
  • 2. 本站的文档不包含任何第三方提供的附件图纸等,如果需要附件,请联系上传者。文件的所有权益归上传用户所有。
  • 3. 本站RAR压缩包中若带图纸,网页内容里面会有图纸预览,若没有图纸预览就没有图纸。
  • 4. 未经权益所有人同意不得将文件中的内容挪作商业或盈利用途。
  • 5. 人人文库网仅提供信息存储空间,仅对用户上传内容的表现方式做保护处理,对用户上传分享的文档内容本身不做任何修改或编辑,并不能对任何下载内容负责。
  • 6. 下载文件中如有侵权或不适当内容,请与我们联系,我们立即纠正。
  • 7. 本站不保证下载资源的准确性、安全性和完整性, 同时也不承担用户因使用这些下载资源对自己和他人造成任何形式的伤害或损失。

评论

0/150

提交评论