英文广告合同范本.doc

1、英文广告合同范本合同的订立是为了保护双方的权益，英文广告合同范本有哪些？以下是为您整理的相关资料，欢迎阅读！英文广告合同范本【一】Unit: (hereinafter referred to as Party A)Advertisers: (hereinafter referred to as Party B)After friendly consultation between Party A and B, in accordance with the principle of mutual benefit and mutualbenefit,thefollowingarticlesarer

2、eachedon PartyAspropaganda and planning on Party Bs entrustment:Article 1: Party A entrusts Party B to publicity planningproject: _The second article: the principle of propaganda and planning Party B provides the whole process of publicity and planning, including advertising planning and design serv

3、ices, providingreferencefor Party As market positioningserving for decision-making.The third one: the way of agencyand market area andParty a commissioned party B to complete the whole process2016 全新精品资料 - 全新公文范文 -全程指导写作独家原创1/16of propaganda and planning, and entrusted the plane design,advertising a

4、gency and other business, fully responsible forthe project publicity and planning.Fourth: the rights and obligations of Party A1.In the agreed period,Party B should be requiredto submitthe relevant propaganda and planning scheme, and the Party Awill assist the organization after the confirmation of

5、themarket investigation.2, it has the right to require Party B to provide writtenopinionsand suggestionsfrom the angle of planningwithinthescope of the Commission.3,Party B willbe requiredto provideParty Awithplanningplans and adjustmentof propaganda strategiesand suggestions.4, to approve the overa

6、ll propaganda strategy formulated byParty B, and to bear all the costs related to publicity andpromotion, advertising and so on.5,payment shallbe paid in accordance withthe agreement ofthe contractwithParty B forthe payment of the publicityandplanning fee and on time.The fifth, the rights and obliga

7、tions of Party B1, the party shall have the right to pay the publicity andplanningfeeinaccordancewiththerequirementsofthe2016 全新精品资料 - 全新公文范文 -全程指导写作独家原创2/16contract.2, in accordance with the requirements of Party A and thedifferentstagesoftheprojectprogress,putforwardadvertisingplan,afterthe approv

8、alof Party A to organizethetheimplementation.3, Party B provides:The newspaper project soft article writing; the project, all kinds of exhibitions, promotions, activities planning.4, bear the claim or other legal liability caused by PartyBs fault.Sixth: the term of agencyPartyA entrustsParty B publi

9、cityplanningperiod is dividedinto: _ years _ month _ to _ _ _ date monthyear;Seventh: standard and mode of payment for project publicityand planning1,publicity planningfees totaling$_ yuan (capital_).2, after the signing of this contract, Party A will pay toPartyBRMB_whole(capital_) for payment.3,af

10、terthe end of the contract,Party A shallpay the balance,2016 全新精品资料 - 全新公文范文 -全程指导写作独家原创3/16namelyRMB_whole_).The eighth article: liability for breach of contract1.Party A is responsible for allthe losses caused(capitalby PartyAs failure to provide relevant license and relevant legal documents and p

11、referential policies for activities.2. If the Party B does not provide the plan of publicity andplanning in time because of Party Bs reasons, Party A shallinvestigate the responsibility or terminate the contract.3. Party A shall have the right to rescind the contract ifPartyA failstopay PartyB publi

12、cityand planningfeesaccording to the agreement.4.In the course of cooperation,the other partyhas the rightto require the other party to bear the related economic lossby disclosing the business secrets or providing the relevantinformation to the third party.5,any partyto terminatethe contractwithouta

13、uthorizationto suspend unilateral breach of contract or shall be borne bythe defaultingparty,must thereforehave caused lossesto theobservant party and liability for breach of contract.6, in the execution of this contract, if there is a forcemajeurefactoraffectingtheexecutionoftherelevant2016 全新精品资料

14、- 全新公文范文 -全程指导写作独家原创4/16provisions, it shall be settled by the two sides and properlyresolved. It is not a breach of contract to terminate the contract or change the relevant provisions of the contract on the basis of the agreement between the two parties.Ninth: Annex1, both parties may supplement t

15、he terms of this contract and sign a supplementary agreement in written form. The supplementary agreement has the same legal effect as this contract.2. The annexes of this contract are all valid parts of the contract and have the same effect.3.Allmatters not specifiedin thiscontractand itsannexesand

16、 supplementary agreements are carriedout in accordance withthe relevantlaws, regulationsand regulationsof the PeoplesRepublic of China.4.The contractis two copies,each partyand Party B has onecopy, all with the same legal effect.5. In the event of a dispute in the performance of thiscontract,the par

17、tiesshallsettlethe disputeby negotiation,negotiationoradjustment,andthepartiesagreetobearbitrated by the Arbitration Commission.6.The contractwillterminatenaturallyafterthe expiration2016 全新精品资料 - 全新公文范文 -全程指导写作独家原创5/16of the contract. If the two parties renew the contract, they shall make a written

18、 opinion to the other party seven days before the expiration of the contract.7. This contract shall come into force on the date of signature or seal of the representatives of the two parties.Party A: Party B:Representative: (signature) representative: (signature)Date: day and date: day and day中文版单 位

19、：广告商：甲、乙双方经友好协商，本着互惠互利的原则，就甲方委托乙方的宣传策划事宜，达成如下条款：第一条：甲方委托乙方宣传策划的项目：_第二条：宣传策划原则乙方按甲方规定，提供全程宣传策划包括广告策划与设计的服务，为甲方市场定位及市场区域提供参改依据，为决策服务。第三条：代理方式甲方委托乙方全权全程宣传策划，并委托平面设计、 广告代理等业2016 全新精品资料 - 全新公文范文 -全程指导写作独家原创6/16务，全面负责本次项目的宣传策划工作。第四条：甲方的权利和义务1 、在约定期限内要求乙方提交有关宣传策划方案，从市场调查依据确认后再由甲方协助组织实施。2 、有权要求乙方在委托范围内从策划角度

20、提供书面意见和建议。3 、要求乙方向甲方提供策划方案及调整宣传策略和建议。4 、批准乙方制订的整体宣传策略，承担有关宣传推广、广告等所需的各项费用。5 、按合同约定与乙方结算宣传策划费并按时支付。第五条、乙方的权利和义务1 、有权按照合同要求甲方支付宣传策划费。2 、负责根据甲方要求和项目进度的不同阶段，提报广告计划，经甲方认可后组织实施。3 、乙方提供：、项目报纸软性文章撰写；、项目各种展销、促销、优惠活动的策划。4 、承担因乙方过错造成的索赔或其他法律责任。第六条：代理期限甲方委托乙方宣传策划期限分为： _ 年_月_日至 _年_月_日止；第七条：项目宣传策划费的给付标准和方式1 、宣传策划

21、费共计￥ _元。2016 全新精品资料 - 全新公文范文 -全程指导写作独家原创7/162 、本合同签订后，甲方即向乙方支付人民币￥_整为预付款。3 、活动结束后，甲方向乙方支付合同余款，即人民币￥ _整.第八条：违约责任1 、因甲方未提供有关许可证及相关法律文件资料、活动优惠政策而造成损失的，则甲方承担全部责任。2 、如因乙方原因，不及时提供宣传策划方案，甲方追究责任或终止合同。3 、甲方如未按照双方约定支付给乙方宣传策划费，乙方有权解除合同。4 、在合作过程中任何一方泄露商业秘密或将有关资料提供给第三人的，另一方有权要求对方承担相关经济损失。5 、任何一方单方擅自中止合同或解除合同均属违约

22、行为，需由违约方承担因此给守约方造成的相关损失和违约责任。6 、本合同执行过程中，如有因不可抗力因素影响有关条款之执行的，应由双方协商，妥善解决，在双方达成一致意见的基础上而中止合同或改变合同的有关条款的不视为违约。第九条：附则1 、双方可对本合同的条款进行补充，以书面形式签订补充协议。补充协议与本合同具有同等法律效力。2 、本合同之附件均为合同有效组成部分，具有同等效力。2016 全新精品资料 - 全新公文范文 -全程指导写作独家原创8/163 、本合同及其附件和补充协议中未规定的事宜，均遵照中华人民共和国有关法律、法规和规章执行。4 、本合同壹式贰份，甲乙双方各执壹份，均具同等法律效力。5

23、 、本合同在履行中如发生争议，双方应协商解决，协商或调节不成的，双方同意由仲裁委员会仲裁。6 、合同期满本合同自然终止。双方如续订合同，应在该合同期满七天前向对方提出书面意见。7 、本合同自双方代表人签字或盖章之日起生效。甲 方：乙 方：代表人： ( 签章 ) 代表人： ( 签章 )日期：年月日 日期： 年 月 日英文广告合同范本【二】Address:Telephone ：Party B: Address:Telephone ：According to the provisions of the contract law of the People s Republic of China an

24、d the relevant laws and regulations, Party B accepts the entrustment of the first party and entrustment with the two parties through consultation.First, entrustment:Two, the way of payment:2016 全新精品资料 - 全新公文范文 -全程指导写作独家原创9/161, Party A shall pay 40% of the total cost of the contract, namely _ yuan (

25、RMB) to Party B, Party B received the money after the start of design.2. Party B shall provide complete design draft. After confirmation by Party A, the total amount of the total costshall be paid. Three. Design time:1, Party B shall provide complete design draft in _ working days.2,Party B shall co

26、mpletethe designwork of partya companycommissioned in _ years _ month _ day (delaytime by partya reason, work time should be postponed).Four.The responsibilitiesandobligationsofthetwoparties:1, Party B shall, according to the requirements of Party Ato finish the related work on time.2, Party A has t

27、he responsibility to fully cooperate withParty B to carry out the work stipulated in this contract andprovide relevant information according to the needs of PartyB. PartyA is responsibleforthe consequences caused by PartyAs delay in the required information.3. Party A shall provide complete design i

28、nformation before2016 全新精品资料 - 全新公文范文 -全程指导写作独家原创10/16thestartofthedesign,due toPartyAsprovisionofincomplete information and changes in content.For structural changes, Party A shall pay the correspondingcost of design changes.4.AfterParty B receivesthecomplete designinformationofParty A,itisdesigned

29、to facilitatethedeterminationofthestyle of Party A, and Party B begins to design the first draftafter the style is determined.5,PartyA has the righttoput forward amendmentsto the worksdesignedbyPartyB.ThefirstdraftPartyA canmake astructuralmodification.Afterthefirstdraft is determined,thestructuralm

30、odificationsshouldbe made. Party A shallpaythe corresponding cost separately.6.The consequences of thedelaydue to the amendmentof PartyA shall be borne by Party A.7,due tothe losscaused by postproduction by PartyA alone,the losscaused by problems inthe design ofthe productis borneby Party B. The leg

31、al liability caused by copyright, for theeconomic disputes shall be borne by Party a.8.During the course of the project, Party B is attached tothebrand of PartyA and shallnotsign any form of cooperationagreement with the customer in the identity of Party B.2016 全新精品资料 - 全新公文范文 -全程指导写作独家原创11/16Five.

32、The agreement on intellectual property rights:1, Party B has the copyright of the works completed by thedesign. After the settlement of all the fees designed by Party A, Party B may transfer the copyright of the works to Party A.2. Before Party A has not paid all the cost of the design,the copyright

33、 of the works designed by Party B shall be attributed to Party B, and Party A does not have any right to the work.3. Party A shall have the right to investigate the legalliability of Party A if it uses or amends the works designed by Party B before the payment is not paid.Six. Liability for breach o

34、f contract:1, Party A terminates the contract before the completion ofthe first draft of the design work. The prepaid expenses haveno rightto request the return. If a party terminates thecontractafterthe completionof the firstdraftof PartyBswork, it shall pay the full design fee.2.IfParty B terminat

35、esthe contractwithoutproper reasons,the fees charged shall be returned to Party A.Seven,ifa party or a party has a disputeover the performanceofthiscontract,itshallbesettledamicablethroughnegotiation. If either party fails to negotiate, any Party A2016 全新精品资料 - 全新公文范文 -全程指导写作独家原创12/16and B can submi

36、t it to the Beijing Arbitration Commission for arbitration.Eight, the contract is effective from the date of signatureby Gai Zhang and both parties. The contract is two copies inone form.Each partyhas one contractsigned by the other party(Gai Zhang), which has the same legal effect.Nine.Ifthereis no matter in thiscontract,the two partiesshalljointlydiscuss and supplement the contract.The contentsof the supplement and modification are equally valid to this contract.Party A: Party B:(signature seal) (signature seal)Date: Date:中文版地址：电话：乙方：地址：电话：依据中华人民共和国合同法和有关法规的规定，乙方接