2024技术信息服务合同

2024技术信息服务合同2024TechnologyInformationServiceContractArticle1:ContractObjectiveThiscontractisestablishedbetweenPartyA(Client)andPartyB(ServiceProvider)tooutlinethetermsandconditionsunderwhichPartyBwillprovidetechnologyinformationservicestoPartyA.Article2:Definitions"TechnologyInformationServices"refertotheservicesprovidedbyPartyBthatinvolvethecollection,processing,anddeliveryoftechnicaldata,information,andinsightstoPartyA."ConfidentialInformation"referstoanyinformationdisclosedbyPartyAtoPartyBthatisnotpubliclyavailableandisdesignatedasconfidential.Article3:ScopeofServicesPartyBagreestoprovidethefollowingtechnologyinformationservicestoPartyA:__________.Thespecificscope,deliverables,andperformancecriteriaoftheservicesaredetailedinAttachment1.Article4:ContractDurationThedurationofthiscontractshallcommenceon__________andshallconcludeon__________.Thecontractmaybeextendedbymutualwrittenagreementofbothparties.Article5:RightsandObligationsofPartyAPartyAhastherighttoreceivethetechnologyinformationservicesaspertheagreedterms.PartyAshallprovidePartyBwithclearinstructionsandnecessaryinformationtoperformtheservices.PartyAshallmaketimelypaymentstoPartyBfortheservicesrendered.Article6:RightsandObligationsofPartyBPartyBhastherighttoreceivepaymentfortheservicesprovidedasperthecontract.PartyBshallperformtheserviceswithduediligence,professionalism,andinaccordancewiththeagreedscope.PartyBshallmaintaintheconfidentialityofallconfidentialinformationreceivedfromPartyA.Article7:ServiceFeesandPaymentTermsThetotalservicefeeforthetechnologyinformationservicesis__________(Currency).PartyAshallmakepaymentstoPartyBaccordingtothefollowingschedule:Aninitialpaymentof__________%uponsigningofthiscontract;Asubsequentpaymentof__________%uponcompletionoftheservicemilestonesasoutlinedinAttachment2;Thefinalpaymentuponsatisfactorycompletionofallservices.Article8:ConfidentialityBothpartiesshallkeepallconfidentialinformationdisclosedinthecourseofthiscontractstrictlyconfidential.Theconfidentialityobligationsshallsurvivetheexpirationorterminationofthiscontractforaperiodof__________years.Article9:IntellectualPropertyRightsAllintellectualpropertyrightstothetechnologyinformationdevelopedorprovidedbyPartyBunderthiscontractshallbeownedbyPartyA.PartyBwarrantsthattheservicesprovideddonotinfringeuponanythird-partyintellectualpropertyrights.Article10:WarrantyandLiabilityPartyBwarrantsthatthetechnologyinformationserviceswillbeperformedinamannerconsistentwithindustrystandards.PartyBshallbeliableforanydamagescausedbyitsbreachofcontractorfailuretoperformtheserviceswiththerequiredprofessionalstandards.Article11:AmendmentsandTerminationThiscontractmayonlybeamendedinwritingandsignedbybothparties.Eitherpartymayterminatethiscontractupon__________days'writtennoticeintheeventofamaterialbreachbytheotherparty.Article12:ForceMajeureNeitherpartyshallbeliableforanyfailureordelayinperformingitsobligationsunderthiscontracttotheextentthatsuchfailureordelayiscausedbyforcemajeure.Theaffectedpartyshallpromptlynotifytheotherpartyoftheforcemajeureeventandusereasonableeffortstomitigateitseffects.Article13:DisputeResolutionAnydisputesarisingoutoforinconnectionwiththiscontractshallberesolvedthroughfriendlyconsultation.Ifconsultationfails,eitherpartymaysubmitthedisputeto__________forarbitrationinaccordancewithitsrules.Article14:GoverningLawThiscontractshallbegovernedbyandconstruedinaccordancewiththelawsof__________.Article15:NoticesAllnotices,requests,demands,andothercommunicationsunderthiscontractshallbeinwritinganddeemeddulygivenwhendeliveredtotheaddressesspecifiedinthiscontractorsuchotheraddressesaseitherpartymayspecifyinwriting.Article16:EntireAgreementThiscontractconstitutestheentireagreementbetweenthepartieswithrespecttothesubjectmatterandsupersedesallprioragreementsandunderstandings,whetherwrittenororal.ForPartyA:__________AuthorizedSignatory:__________Address:__________ContactNumber:__________Date:__________ForPartyB:__________AuthorizedSignatory:__________Address:__________ContactNumber:__________Date:__________Article17:AttachmentsAttachment1:DetailedScopeofTechnologyInformationServicesincludingspecificobjectives,tasks,andexpectedoutcomes.Attachment2:ServiceMilestoneDeliverablesandcorrespondingpaymentschedule.Attachment3:DescriptionofConfidentialInformationandNon-DisclosureAgreement.Attachment4:IntellectualPropertyRightsAssignmentandLicenseAgreement.Article18:BreachofContractandDeterminationBreachofContract:Abreachoccurswhenonepartyfailstofulfillitsobligationsunderthecontract,includingbutnotlimitedto:Non-paymentorlatepaymentforservices;Failuretodeliverservicesasstipulated;Breachofconfidentiality.Determination:Abreachisdeterminedby:Writtennoticeofthebreachtotheoffendingparty;Evaluationofthebreachbasedontheevidenceprovided;Opportunityforthebreachingpartytoremedythebreachwithinaspecifiedperiod.Article19:LegalTermsandDefinitionsTechnologyInformationServices:Servicesthatinvolvetheprovisionoftechnicaldata,analysis,andinsights.ConfidentialInformation:Informationthatisnotpubliclyavailableandisdisclosedbyonepartytotheotherunderadutyofconfidentiality.ForceMajeure:Eventsorcircumstancesbeyondthecontrolofthepartiesthatpreventordelaytheperformanceofcontractualobligations.Article20:IssuesandResolutionsinExecutionChangesinScope:Anychangesinthescopeofworkshallbedocumentedinwritingandagreeduponbybothparties,withadjustmentstotheservicefeesandtimelineasnecessary.TechnicalDifficulties:IfPartyBencounterstechnicalissues,itshallpromptlyinformPartyAandproposesolutionsoralternatives.Delays:Intheeventofdelays,thepartiesshallnegotiatearevisedtimelineandanynecessaryadjustmentstotheservicefees.Article21:ApplicableScenariosThiscontracttemplateisapplicabletoavarietyoftechnologyinformationserviceengagements,suchasmarketresearch,technicalconsulting,anddataanalyticsservices.Thecontractensuresthattheserviceengagementsareconductedinaprofessionalandlegallybindingmanner,coveringallnecessaryaspectsoftheserviceprovision.Attachment1:DetailedScopeofTechnologyInformationServicesServiceDescription:Acomprehensivedescriptionoftheservicestobeprovided,includingthemethodologyandtoolstobeused.PerformanceMetrics:Specificmetricstoevaluatethequalityandeffectivenessoftheservices.Attachment2:ServiceMilestoneDeliverablesandPaymentScheduleMilestones:Alistofdeliverableswithcorrespondingdeadlines.PaymentSchedule:Detailedpaymenttermsassociatedwitheachmilestone.Attachment3:DescriptionofConfidentialInformationandNon-DisclosureAgreementConfidentialInformation:Acleardefinitionofwhatconstitutesconfidentialinformation.Non-DisclosureCommitment:Theobligationsofbothpartiesregardingtheprotectionofconfidentialinformation.Attachment4:IntellectualPropertyRightsAssignmentandLicenseAgreementOwnership:Theassignmentofintellectualpropertyrightstothetechnologyinformationdevelopedunderthecontract.License:ThetermsunderwhichPartyAisgrantedalicensetousetheintellectualproperty.Article22:ContractModificationandTerminationModification:Anymodificationstothecontractmustbeagreeduponbybothpartiesanddocumentedinwriting.Termination:Thecontractmaybeterminatedbyeitherpartyupontheoccurrenceofcertainconditions,suchasbreachofcontractorforcemajeure.Article23:InterpretationoftheContractTheinterpretationofthiscontractsh