修订装修分包合同劳务

修订装修分包合同劳务合同编号：__________revisiondecorationsubcontractorcontractlaborBETWEENPartyA:____________________________Address:____________________________LegalRepresentative:____________________________PartyB:____________________________Address:____________________________LegalRepresentative:____________________________ThePartieshaveenteredintoadecorationsubcontractorcontract(hereinafterreferredtoasthe"PrincipalContract")forthedecorationprojectofPartyA'spropertylocatedat____________________________(hereinafterreferredtoasthe"Project").InordertoimplementthePrincipalContractmoreeffectivelyandensurethesmoothprogressoftheProject,thePartieshaveagreedtorevisethePrincipalContractandenterintothisRevisionDecorationSubcontractorContractLabor(hereinafterreferredtoasthe"Contract").1.ScopeofWork1.1PartyBshallprovidethelaborandmaterialsrequiredforthedecorationworksspecifiedinthePrincipalContract,andshallperformthedecorationworksinaccordancewiththerequirementsandstandardssetforthinthePrincipalContract.2.PaymentTerms2.2AnyadditionalcostsorexpensesincurredPartyBinthecourseofperformingthedecorationworksshallbebornePartyB,unlesssuchcostsorexpensesarecausedthefaultofPartyAoritsagents.3.Warranty3.2Intheeventthatanydefectsoccurwithinthewarrantyperiod,PartyBshall,atitsownexpense,promptlyrepair,replace,orrefundtheaffectedpartsorworks,subjecttothetermsandconditionssetforthinthePrincipalContract.4.Liability4.1PartyBshallbeliableforanylossesordamagescausedtoPartyAoritspropertyasaresultofitsbreachoftheContractoranyactoromissionofitsemployees,agents,orsubcontractors.4.2PartyAshallbeliableforanylossesordamagescausedtoPartyBoritspropertyasaresultofitsbreachoftheContractoranyactoromissionofitsemployees,agents,orsubcontractors.5.Confidentiality5.2TheconfidentialityobligationsetforthinthisArticleshallsurvivetheexpirationorterminationoftheContract.6.DisputeResolution6.1AnydisputesarisingoutoforinconnectionwiththeContractshallberesolvedthroughfriendlynegotiations.Ifthenegotiationsfailtoresolvethedisputes,eitherPartymaysubmitthedisputestothe____________________________forarbitrationinaccordancewithitsrulesandregulations.6.2ThedecisionofthearbitrationpanelshallbefinalandbindingupontheParties,andthePartiesagreetoexecutethedecisionwithoutdelay.7.Miscellaneous7.1ThisContractconstitutestheentireagreementbetweenthePartieswithrespecttothesubjectmatterhereof,andsupersedesallprioragreements,understandings,negotiations,anddiscussions,whetheroralorwritten,oftheParties.7.2ThisContractmaybeamendedormodifiedonlyawritteninstrumentexecutedbothParties.7.3IfanyprovisionofthisContractisheldtobeinvalid,void,orunenforceable,theremainingprovisionsshallremaininfullforceandeffect,andthePartiesagreetoreplacetheinvalid,void,orunenforceableprovisionwithavalid,enforceableprovisionthatbestreflectstheoriginalintentoftheParties.INWITNESSWHEREOF,thePartieshaveexecutedthisRevisionDecorationSubcontractorContractLaborasofthedatefirstabovewritten.PartyA:____________________________By:____________________________Name:____________________________Title:____________________________Date:____________________________PartyB:____________________________By:____________________________Name:____________________________Title:____________________________Date:____________________________一、附件列表：1.装修分包合同原文件2.装修设计图纸3.材料规格说明书4.工程进度计划表5.质量检验标准6.付款凭证7.工程变更通知单8.验收报告二、违约行为及认定：1.未能按照合同约定的时间完成工作：指超过合同规定的工程进度计划表所确定的完成日期。2.提供的材料不符合合同规定的质量标准：指材料未能满足合同中约定的质量要求。3.未能按照合同要求进行修复或更换：指在质保期内，未能按照合同约定进行修复、更换或退款。4.泄露合同保密信息：指未经许可，将合同中的商业、财务、技术或其他保密信息告知无关方。5.未能执行仲裁裁决：指任何一方未能按照仲裁裁决的内容执行。三、法律名词及解释：1.装修分包合同：指由主合同当事人（发包方）与分包方之间签订的，约定分包方按照主合同的约定完成一定的装修工作的合同。2.质保期：指合同中约定的，分包方对完成的装修工程承担质量保证的时间期限。3.违约行为：指合同当事人不履行合同义务或者履行合同义务不符合约定的行为。4.仲裁：指合同双方按照事先约定的仲裁条款，通过仲裁机构对合同争议进行解决的方式。5.保密信息：指在合同执行过程中，涉及商业秘密、技术秘密或其他需要保密的信息。四、执行中遇到的问题及解决办法：1.工程进度延误：如遇不可抗力等因素导致工程进度延误，应立即通知对方，并协商调整工程进度计划。2.材料质量问题：发