优美国华盛顿州工程总承包合同 （价款加杂费）（中英文对照）正式标准模板

美国华盛顿州工程总承包合同（价款加杂费）（中英文对照）美国华盛顿州工程总承包合同（价款加杂费）（中英文对照）IMPERIUMGRAYSHARBORLLCCONSTRUCTIONAGREEMENT（COSTPLUSFEE）中英文3万余字，word文档。学术交流请私信或评论留言TABLEOFCONTENTS总目录1.TheWork第1条工程2.ContractDocuments.第2条.合同文件3.TotalPrice.第3条工程总价款4.Contractor’sFee.第4条承包商的杂费5.CostoftheWork.第5条工程价款6.CostsNottobeReimbursed.6.不予偿付的费用。7.FinancingArrangements.7.融资安排8.Payment.8.款项支付9.ContractTimes.9.合同履行时间10.Changes.10.变更11.SiteInvestigation.11.工地现场调查12.ClaimsforDamages.12.索赔损害赔偿13.Delay.13.工期延误14.Contractor’sPaymentObligations.14.承包商的付款义务15.Liens.15.留置权16.Warranty.16.保修承诺17.DefectiveWork.17.瑕疵工程的处理18.Cleanup.18.清理场地19.SiteAccess.19.场地通行权20.PermitsandInspections.20.许可证和检验21.As-BuiltDrawings.21.竣工图22.Owner’sConstructionandSeparateContracts.22.业主的施工和单独的合同23.SafetyandEnvironment.23.安全和环境24.CompliancewithLaws.24.遵守法律25.IndependentContractor.25.独立承包方26.Subcontracts.26.转包合同27.Assignment.27.合同义务的转让28.Aesthetics28.业主对美学效应的决定29.Intentionallyomitted.29.本条款内容特意省略30.OwnershipofDrawingsandSpecifications.30.图纸和规格的所有权31.Indemnity.31.赔偿32.LimitationofLiability.32.责任限定33.TitleandRiskofLoss.33.所有权和损失风险34.Contractor’sInsuranceObligations.34.承包商的保险义务35.Owner’sInsuranceObligations.35.业主的保险义务36.Owner’sFailuretoPay.36.业主未能付款37.TerminationandCancellation.37.合同终止和撤销38.ForceMajeure.38.不可抗力39.Exclusivity.39.专属权40.DisputeResolution.40.争议的解决41.GoverningLaw;Forum;AttorneyFees.41.管辖法律、法庭、律师费42.Modification;EntireAgreement.42.变更，协议的完整性43.Audit.43.审计44.Waiver.44.不构成权利放弃45.Severance.45.条款的可分割性46.JointDrafting.46.本协议由当事方共同草拟部分章节示例如下：9.ContractTimes.9.合同履行时间TimeisoftheessenceofthisAgreement,andspecificallyoftheprovisionsofthisSection9,whichsetsforththetimesofperformanceforvariouscomponentsofthisAgreement(the“ContractTimes”).时间是本协议的关键，特别是第9条的规定，其中规定了本协议各组成部分的履行时间（"合同时间"）。9.1TheContractorhasalreadycommencedperformanceoftheWorkpursuanttoaLimitedNoticetoProceedexecutedbytheOwnerandtheContractoronthedateof.9.1承包商已经根据业主和承包商在之日按照签署的限定开工通知开始实施工程。9.2BoththeOwnerandContractorshallperformtheirobligationsunderthisAgreementincompliancewiththeProjectScheduleattachedasExhibitD,subjecttomodificationsofsuchProjectScheduleconsistentwithchangesintheContractTimespursuanttoSections10and13.9.2业主和承包商均应按照附件D中的项目日程表履行其在本协议下的义务，但可根据第10条和第13条对该项目日程表进行符合合同时间变更的修改。9.3TheContractorshallachieveMechanicalCompletion(ashereinafterdefined)oftheWorknotlaterthantheapplicabledatespecifiedonExhibitA,subjecttochangesintheseContractTimespursuanttoSections10and13(the“GuaranteedMechanicalCompletionDate”).MechanicalCompletionshallbeachievedwhen:9.3承包商应不迟于附件A规定的适用日期实现工程的机械完工（按照下文规定），但可根据第10和13条对这些合同时间进行变更（"保证机械竣工日期"）。机械竣工应在以下情况下实现：。(i)theWorkiscompletedinaccordancewiththisAgreement,exceptforpunchlistitems;(ii)theOwnerhasreceivedanyrequiredtemporaryorfinalcertificateofoccupancyfromthegovernmentalagencywithjurisdictionovertheProject;and(iii)theregisteredarchitectsorengineerswhodesignedportionsorcomponentsoftheWorkhaveissuedcertificatesofMechanicalCompletionastothoseportionsorcomponents.TheOwnershallnotoccupyorutilizetheWorkuntilitismechanicallycompletedexceptasagreedinwritinginadvancebytheContractor.(i)工程已按照本协议完成，但未完成的项目除外；(ii)业主已从对项目有管辖权的政府机构获得任何所需的临时或最终使用证书；以及(iii)设计工程部分或部件的注册建筑师或工程师已对这些部分或部件出具机械完工证书。除非承包商事先书面同意，否则业主不得占用或使用该工程，直到其机械竣工。9.4TheContractorshallachieveFinalCompletion(ashereinafterdefined)oftheWorknotlaterthantheapplicabledatespecifiedonExhibitA,subjecttochangesintheseContractTimespursuanttoSections10and13(the“GuaranteedFinalCompletionDate”).FinalCompletionshallbeachievedwhen:(i)MechanicalCompletionoftheWorkhasbeenacknowledgedbytheOwnerandengineerinwriting;(ii)finallienwaiversandreleasesandotherdocumentsorinspectionsreasonablyrequiredbyOwner’sengineerorlenderhavebeendelivered;(iii)theContractorhasdeliveredthejobbooksandas-builtdrawings;(iv)alltheContractor’ssupplies,personnelandrubbishhavebeenremovedfromthesite;(v)allpunchlistitemshavebeencompleted(orotherwiseresolvedbyagreementoftheOwnerandtheContractor;and(vi)LiquidatedDamages,ifapplicable,havepaidtoOwner.9.4承包商应不迟于附件A规定的适用日期实现工程的最终竣工（按照下文所规定），但可根据第10条和第13条对合同时间进行变更（"保证最终竣工日期"）。最终竣工应在以下情况下实现(i)业主和工程师以书面形式认可工程的机械部分竣工；(ii)最后的留置权放弃和结清以及业主的工程师或贷款人合理要求的其他文件或检查已经交付；(iii)承包商已经交付工程簿和竣工图。(iv)承包商的所有用品、人员和垃圾已从工地上移走；(v)所有清单上的项目都已完成（或经业主和承包商同意解决）；(vi)违约金，如果适用，已支付给业主。9.5Inlieuofactualdelaydamages,theOwnerandContractoragreethatifMechanicalCompletionisnotachievedbytheapplicableGuaranteedMechanicalCompletionDate,theamountoftheOwner’sactualdamageswillbedifficulttodetermine.Accordingly,theOwnerandtheContractoragreethatintheeventtheContractorfailstoachieveMechanicalCompletionbytheapplicableGuaranteedMechanicalCompletionDate,theContractorshallpaytotheOwnerasliquidateddamagestocompensatetheOwnerfordamagesrelatedtothedelayedcompletionoftheWork(“LiquidatedDamages”)seventy-fivethousanddollarsperweek($75,000/week)foreverycalendarweekContractorfailstomeettheGuaranteedMechanicalCompletionDatereferencedinparagraph9.3(lessthenfullweeksshallbepro-rated;provided,however,thattheaggregateamountofliquidateddamagescannotexceedsixhundredthousanddollars($600,000).9.5为了代替实际的延迟损害赔偿，业主和承包商同意，如果在适用的保证机械部分竣工日期之前没有实现机械竣工，业主的实际损害赔偿金额将很难确定。因此，业主和承包商同意，如果承包商未能在适用的保证机械竣工日期前实现机械竣工，承包商应向业主支付违约金，以补偿业主与延迟完成工程有关的损失（即"违约金"），每周7.5万美元（75,000美元/周），用于承包商未能达到第9条中涉及的保证机械竣工日期的每个日历周（不足整周应按比例计算）；但是，违约金总额不能超过六十万美元（600,000美元）。9.6TheOwnerandContractoragreethatifMechanicalCompletionfortheWorkoccurspriortotheGuaranteedMechanicalCompletionDate,theOwnershallpaytotheContractorasabonusseventy-fivethousanddollarsperweek($75,000/week)foreverycalendarweektheWorkreachesMechanicalCompletionpriortoitsGuaranteedMechanicalCompletionDate(lessthenfullweeksshallbepro-rated);providedthattheaggregateamountofthebonusshallnotexceedthreehundredthousanddollars($300,000).9.6业主和承包商同意，如果工程的机械完工时间早于保证机械完工日期，业主应向承包商支付每周七万五千美元（75,000美元/周）的奖金，用于在保证机械竣工日期之前达到机械竣工的每一个日历周（不足一周应按比例计算）；但奖金总额不得超过三十万美元（$300,000）。10.Changes.10.变更WithoutinvalidatingthisAgreement,theOwnerorContractormayorderchangesintheWorkwithinthegeneralscopeofthisAgreementconsistingofadditions,deletionsorotherrevisions(eacha“ChangeOrder”).ItisexpresslyunderstoodandagreedthattheContractorshallnotbeentitledtoadditionalcompensationoranextensionoftheContractTimesforanyextraoradditionalworkorforworkoutsidethescopeoftheAgreement,exceptassetoutinthisSection10.在无损本协议效力的情况下，业主或承包商可以在本协议的一般范围内指令对工程进行变更，包括增加、删除或其他修订（以"更改单"分别处理）。各方同意，承包方无权就任何额外的或附加的工程或协议范围以外的工程获得额外的补偿或延长合同时间，但本第10条规定的情况除外。10.1TheOwnerandContractorshallenterintoawrittenChangeOrdersignedbybothpartiesstatingthechangedWorktobeperformed,anyagreedchangesintheContractor’sFee,andanyagreedchangesintheContractTimes.AnyextraorchangedworkperformedwithoutpriorwrittendirectionorapprovalofOwnershallnotbecompensatedbyOwner.10.1业主和承包商应签订一份由双方签署的书面变更单，说明要实施的变更工程、承包商费用的任何商定变更以及合同时间的任何商定变更。任何未经业主事先书面指示或批准而进行的额外或变更的工程，业主不得给予补偿。10.2IftheOwnerandContractorareunabletoagreeonthechangesintheContractor’sFeeorthechangesintheContractTimes,theOwnermaydirecttheContractorinwritingtoperformthechangedWorkandtheContractorshallimmediatelyperformsuchWork.Insuchcase,andsubjecttoSection4above,(i)theContractor’sFeeshallbecalculatedinaccordancewiththefollowingmark-upschedule,asappliedtotheactualchangeintheCostsoftheWork:10.2如果业主和承包商无法就承包商费用的变更或合同时间的变更达成一致，业主可以书面指示承包商实施变更的工程，承包商应立即实施这些工程。在这种情况下，在遵守上述第4条的前提下，（i）承包方的费用应按照以下加价表计算，并适用于工程费用的实际变更。20%onstafflaborandsupervision;15%ondirectandfabricationlabor;10%onmaterialsandequipmentand5%onSubcontractors;and(ii)theContractTimesshallbeadjustedbasedonthereasonableactualimpactontheContractor’sperformanceoftheWork.IfthepartiesareunabletoagreeonthechangesintheContractor’sFeeorintheContractTimes,theOwnershalldetermineanysuchchanges,whichshallbesubjecttoarbitrationifdemandedbytheContractor.20%的人员劳动和监督；15%的直接劳动和制造劳动；10%的材料和设备以及5%的分包商；以及（ii）合同时间应根据对承包商履行工程的合理实际影响进行调整。如果双方无法就承包方费用或合同时间的变化达成一致，业主应确定任何此类变化，如果承包方提出要求，应进行仲裁。11.SiteInvestigation.11.工地现场调查TheContractorwarrantsthat,byexamination,ithassatisfieditselfastothegeneralnatureandlocationoftheWork,thegeneralcharacter,quantityandkindofmaterialstobeencountered,theequipmentrequiredandthegeneralconditionsandothermatterswhichmayinanymanneraffecttheWork.TheOwnershallfurnishallsitesurveysandlegaldescriptionsrequiredfortheWork,ifany,andContractorshallbeentitledtorelyuponthesame.Contractorexpresslydisclaimsallliabilityforlatentorsubsurfaceconditions.Notwithstandingtheforegoing,ContractorshallberesponsibleforlocatingandmanagingtheWorkaroundanyexistingundergroundpipesandelectricallines.承包商保证，通过审查，它已对工程的一般性质和位置，将遇到的材料的一般性质、数量和种类，所需设备以及一般条件和其他可能以任何方式影响工程的事项感到满意。业主应提供工程所需的所有现场调查和法律所规定的描述（如有），承包商应有权依赖这些。承包商明确表示对潜在的或地下的条件不承担任何责任。尽管有上述规定，承包方应负责定位和管理任何现有地下管道和电线周围的工程。12.ClaimsforDamages.12.索赔损害赔偿IftheContractorhasanyclaimforadditionalcompensationorotherdamagesagainsttheOwner,theContractorshallgivetheOwnerwrittennoticeofsuchclaimwithinten(10)daysaftertheContractorobtainsknowledgeoftheeventallegedtohavegivenrisetotheclaim.IftheContractorfailstogivesuchnotice,theclaimshallbedeemedwaivedandforeverdischarged.如果承包方对业主有任何额外的赔偿或其他损失的要求，承包方应在知悉据称引起索赔的事件后十（10）天内向业主发出书面索赔通知。如果承包商未能发出这样的通知，则应视为放弃并不再提出索赔。13.Delay.13.工期延误IftheContractorisready,ableandwillingtoworkbutisdelayedatanytimeduringtheprogressoftheWorkbyanyactorneglectoftheOwner,changesorderedintheWorkoraneventofForceMajeure(asdefinedinSection38),theContractTimesshallbeextendedbythenumberofcalendardaysthattheWorkasawholeisdelayedpursuanttothisSection13.如果承包商准备就绪，能够并愿意实施工程，但由于业主的任何行为或疏忽，在工程进展中的任何时候被延误，在工程中指令的变更或不可抗力的事件（如第38条所规定），合同工期应根据本第13条的规定对整个工程被延迟的日历天数做延展。TheContractorshallsubmitanyclaimforanextensionoftimetotheOwner,inwriting,withinten(10)daysafterthecommencementofthedelay.Onlyoneclaimisnecessaryintheeventofacontinuingdelay.Thewrittenclaimforextensionoftimeshallstatethenumberofdaysclaimedandthereasonforthedelay.Anyclaimforatimeextensionwhichisnotpresentedinaccordancewithallrequirementsofthisparagraphshallbedeemedwaivedandforeverdischarged.承包商应在延误开始后十（10）天内书面向业主提出任何延展工期的要求。在持续延误的情况下，只需要提出一次索赔。延展工期的书面要求应说明要求的天数和延误的原因。任何未按照本段所有要求提出的延期要求，应被视为放弃并不再提出。13.1IfadverseweatherconditionsorothereventsofForceMajeurearethebasisforaclaimforanextensionoftheContractTimes,suchclaimshallbeallowedonlytotheextentitisdocumentedbydatasubstantiatingthattheweatherconditions(i)wereunusuallyseverefortheAberdeenareaduringtheperiodoftimeinquestion,(ii)unusuallyseveretobedefinedasoccurrencesofinexcessof1.50inchesofprecipitationfor2ormoreconsecutivedays,and/orprecipitationinexcessof2.00inchesofprecipitationfor1ormoreconsecutivedays,and/orprecipitationinexcessof1.00inchesfor3ormoreconsecutivedays,asmeasuredatHoquiam’sBowermanAirport,(iii)couldnothavebeenreasonablyanticipatedand(iiii)hadanadverseeffectonthescheduledperformanceoftheWork.13.1如果恶劣的天气条件或其他不可抗力事件是要求延长合同工期的依据，这种要求应仅在有数据证明天气条件(i)在有关时间段内对阿伯丁地区异常严重的情况下被允许，(ii)异常严重是指发生超过1.50英寸的降水连续2天或更多，和/或超过2.00英寸的降水连续1天或更多，和/或超过1.00英寸的降水连续3天或更多，如在霍奎姆的鲍尔曼机场测量，（iii）不能合理预期和（iiii）对工程的预定实施有不利影响。13.2AnextensionoftheContractTimesshallbeallowedonlytotheextentthatsuchdelaywasnotcausedbyanyfaultornegligenceoftheContractor,Subcontractors,anyonedirectlyorindirectlyemployedbyanyofthemorforwhoseactsanyofthemmaybeliable.13.2只有在这种延误不是由承包商、分包商、他们中任何一方直接或间接雇用的任何人或他们中任何一方可能对其行为负责的任何过失或疏忽造成的情况下，才应允许延长合同工期。13.3IftheWorkisstoppedorsuspendedbyorderofanycourtorgovernmentalauthority,withinseven(7)daysafterreceiptofnoticethatsuchWorkstoppageorsuspensionisremoved,theContractorshallcompletetheWorkasexpeditiouslyasreasonablypossible.Intheeventofsuchstoppageorsuspension,theContractorshallbeentitledtoanextensionintheContractTimesequaltothelengthofthedelay(thelengthofthestoppageorsuspensionplustheseven(7)orfewerdaysafternoticewithinwhichtheContractorrecommencestheWork)plusanequitableincreaseintheContractor’sFee.13.3如果工程因任何法院或政府当局的命令而停止或暂停，在收到取消这种工程停顿或暂停的通知后七（7）天内，承包方应在合理范围内尽快完成工程。在这种停工或暂停的情况下，承包方应有权延长合同工期，相当于延误的期间（停工或暂停的期间加上通知后的七（7）天或更少的时间，承包方重新开始工程），加上承包方费用的合理增加。14.Contractor’sPaymentObligations.14.承包商的付款义务TheContractorshallpayallofitsobligationsarisingoutoforinconnectionwiththeWorkinatimelymanner.UponreasonableevidencethatoneormoreSubcontractorshavenotbeenorwillnotbepaid,theOwnermaypayanyoftheContractor’spaymentobligationsdirectlytotheclaimantorbymultiplepayeechecktotheContractorandtheclaimantandpartiesininterveningtiers,ifany,anddeducttheamountofsuchpaymentfromamountsdueortobecomeduetotheContractor.UpontheOwner’swrittenrequest,theContractorshallfurnishtotheOwnerallinformationrequiredtofacilitatesuchdirectormultiplepayeepayments,includingwithoutlimitationacompletelistingofoutstandingamountsowedtoallSubcontractors.承包商应及时支付由工程引起的或与工程有关的所有债务。如果有合理的证据表明一个或多个分包商没有或不会得到付款，业主可以将承包商的任何付款债务直接支付给索赔人，或通过多个收款人的支票支付给承包商和索赔人以及中间层的各方（如有），并从应付给或将应付给承包商的款项中扣除这种付款的数额。根据业主的书面要求，承包商应向业主提供所有必要的信息，以促进这种直接或多个收款人的付款，包括但不限于欠所有分包商的未付款项的完整清单。15.Liens.15.留置权TheContractorshallkeeptheProjectandProjectpropertyfreeandclearofallconstructionliensarisingoutoftheWork.IfanyliensarisingoutoftheWorkarefiledbyanypersonorentity,includingwithoutlimitationanySubcontractor,theContractorshall,atitscostandwithinten(10)daysafterdemandfromtheOwner,satisfysaidlienorpostandperfectabondunderapplicablelawsoastoremovethelienfromtheProjectandProjectproperty.Theabovenotwithstanding,nothinghereinshallprecludeordepriveContractoroftherighttofileandmaintainalienontheProjectorProjectpropertyintheeventofnon-paymentbyOwner.承包商应保持项目和项目财产不存在因工程而产生的所有建筑留置权。如果任何个人或实体，包括但不限于任何分包商，提出任何工程留置权，承包商应在业主要求后的十（10）天内，以其价款清偿上述留置权或交易账目张贴和完善债券，以消除项目和项目财产的留置权。尽管有上述规定，但在业主未付款的情况下，本条款不应排除或剥夺承包商对项目或项目财产提出和维持留置权的权利。16.Warranty.16.保修承诺16.1TheContractorwarrantstotheOwnerthatthematerialsandequipmentfurnishedunderthisAgreementwillbe(a)newandofgoodquality;(b)freefromdefectsinmaterialsandworkmanship,unlessotherwiseapprovedinwritinginadvancebytheOwner,and(c)thattheWorkwillbeperformedinagoodandworkmanlikemannerandinaccordancewiththePlansandallapplicablecodes,lawsandstandards.16.1承包商向业主保证，根据本协议提供的材料和设备将是(a)新的和高质量的；(b)没有材料和工艺上的缺陷，除非事先得到业主的书面批准，以及(c)工程将以良好和精湛的方式进行，并符合计划和所有适用规范、法律和标准。TheContractorshallcollectandsubmittotheOwner,uponMechanicalCompletionoftheWork,allwarrantiesfromSubcontractorssupplyingmaterials,equipmentorcomponentsincorporatedintotheProject,andtheContractorherebyassignstotheOwneralloftheContractor’srightsundersuchwarranties.TheContractoragreesthatsuchwarrantiesfromthoseSubcontractorsreferencedinExhibitFshallcomplywiththerequirementssetoutinExhibitF.承包商应在工程机械完工收集并向业主提交材料、设备或部件的分包商对项目的所有保证，并且承包商在此将承包商在这些保证下的所有权利转让给业主。承包商同意，附件F中提到的那些分包商的这种保证应符合附件F中的要求。16.2TheContractorwillrecommendtoOwnerallprocessandconstructionimprovementsthatitbelievesingoodfaithwouldoptimizetheProjectconstructionandoperations,providedthatContractor’sliabilityforbreachesofsuchwarrantyshallbelimitedtoinstancesofgrossnegligenceorwillfulmisconduct.16.2承包商将向业主推荐其真诚地认为可以优化项目建设和运营的所有工艺和施工改进措施，但承包商对违反这种保证的责任应限于严重疏忽或故意不当行为的情况。16.3Thefollowingshallgovernthedurationsofthewarrantiesdescribedabove.ThebasewarrantyperiodwillcommencewhenMechanicalCompletionhasbeenachievedandwillcontinueforthelesserof(i)twelve(12)monthsfromtheapplicableGuaranteedMechanicalCompletionDate;or18monthsaftertheapplicableFinalCompletionDate(“BaseWarrantyPeriod”).WarrantyforanyrepairsorreplacementsshallcommenceonthedatetherepairorreplacementiscompletedandcontinueuntilthelateroftheexpirationoftheBaseWarrantyPeriodorsix(6)monthsfromthedateofcompletionoftherepairorreplacementandshallnotexceedamaximumofthirty(30)monthsfromtheMechanicalCompletionDate(the“RepairWarrantyPeriod”)(theBaseWarrantyPeriodplustheRepairWarrantyPeriodarecollectivelyreferredtoasthe“WarrantyPeriod”).Contractorshall,asmitigationofthedamagessufferedbytheOwner,atContractor’sowncostandexpense(includingthecostoflaborandequipment)promptlyrepairorreplacewithmaterialsofnewandgoodqualityanyWorkormaterialswhichfailtocomplywiththewarrantyduringtheWarrantyPeriod.16.3上述保证的期限应遵循以下规定。基本保证期将从实现机械竣工时开始，并将持续到(i)从适用的保证机械完成日期开始的十二(12)个月；或适用的最终完成日期之后的18个月（"基本保证期"），以较低者为准。任何修理或更换的保证应从修理或更换完成之日开始，并持续到基本保证期届满或从修理或更换完成之日开始的六（6）个月（以较晚者为准），并且不应超过从机械完成日期开始的最多三十（30）个月（"修理保证期"）（基本保证期加上修理保证期统称为"保证期"）。承包商应在保修期内及时修理或用新的、质量好的材料更换任何不符合保修要求的工程或材料，以减轻业主的损失，费用由承包商自行承担（包括劳动力和设备的费用）。17.DefectiveWork.17.瑕疵工程的处理TheWorkshallbesubjecttoobservationandapprovalbytheOwnerandrepresentativesofgovernmentalagencieswithjurisdictionovertheProject.Withoutlimitingtheeffectofthepriorsentence,allportionsorcomponentsoftheWorkdesignedbyregisteredarchitectsorengineersshallalsobesubjecttotheirobservationandapproval.TheContractorshallpromptlycorrect,atnocosttotheOwner,allWorkreasonablyrejectedbytheOwnerandallWorkrejectedbysuchagencyrepresentatives.ShouldtheContractorfailtocorrectrejectedWork,theOwnermaycorrectsuchWorkandtheContractorshallpaytheOwner’sactualcostsofcorrection.本工程应接受业主和对本工程有管辖权的政府机构代表的检测和批准。在不限制前述规定效力的情况下，由注册建筑师或工程师设计的工程的所有部分或组件也应接受他们的检测和批准。承包商应及时纠正被业主合理拒绝的所有工程和被这些机构代表拒绝的所有工程，而不需要业主承担任何费用。如果承包商未能纠正被拒绝的工程，业主可以纠正这些工程，承包商应支付业主的实际纠正费用。18.Cleanup.18.清理场地TheContractoratalltimesshallkeeptheProjectpremisesreasonablyfreefromwaste,debrisandotherexcessmaterialscausedbytheWork,andshallleavethepremisesin“broomclean”conditionattheendofeachdayofWork.UponbothsubstantialandfinalcompletionoftheWork,theContractorshallremoveallwaste,debris,tools,equipmentandexcessmaterialsfromtheProjectsite,shallproperlydisposeofallsuchitems,andshallleavethesiteinaneatandorderlycondition.ShouldtheContractorfailtoperformitsobligationsunderthisSection,theOwnermaydosoattheContractor’sexpense.承包商在任何时候都应保持项目场地合理地无废物、碎片和其他由工程引起的多余材料，并应在每天工程结束时使场地处于"扫帚清洁"状态。在工程基本完成和最终完成时，承包方应从项目现场清除所有废物、碎片、工具、设备和多余的材料，应妥善处理所有这些物品，并应使现场处于整洁有序的状态。如果承包方未能履行本节规定的义务，业主可以这样做，费用由承包方承担。19.SiteAccess.19.场地通行权TheContractorshallallowtheOwneranditsrepresentativesaccessatallreasonabletimestotheProjectsiteandtotheWorkwhereverbeingperformed.InvisitingtheProjectsiteandtheWork,theOwneranditsrepresentativesshallnotunreasonablyinterferewithordelaytheperformanceoftheWork,whetherperformedbytheContractororSubcontractors.承包商应允许业主及其代表在所有合理的时间进入项目现场和正在实施的工程。在查看项目现场和工程时，业主及其代表不应不合理地干扰或拖延工程的进行，无论是由承包商还是分包商进行。20.PermitsandInspections.20.许可证和检验IfrequestedbyOwner,theContractorshallsecureandinitiallypayforthebuildingpermit,plancheckfees,andallotherpermitsandfees,testsandinspectionsbygovernmentalagenciesrequiredandnecessaryfortheperformanceandcompletionoftheWorkbytheContractorandSubcontractors.TheOwnershallreimbursetheContractorforthecostofthebuildingpermit(butthereshallbenoContractorfeeormarkupthereon).TheContractor’sothercostsincurredunderthisSection20shallbereimbursedbytheOwneraspartoftheCostoftheWork,excepttotheextenttestsorinspectionshereunderdisclosedefectiveornonconformingWorkcausedbythefaultornegligencereferencedinSection6.6.如果业主要求，承包商应确保并先行支付建筑许可证、计划检查费，以及承包商和分包商执行和完成工程所需的政府机构的所有其他许可证和费用、检测和检查。业主应向承包商偿付建筑许可证的费用（但不应该有承包商的费用或加价）。承包商根据第20条所产生的其他费用应作为构成价款的一部分由业主偿还，除非根据本条规定的检测或检查发现有缺陷或不符合要求的工程是属于第6.6条中规定的过失或疏忽造成的。20.1TheOwnershallcontractandpayforalltestsandinspectionsoftheWorkbythirdpartiesrequiredandnecessaryfortheperformanceandcompletionoftheWorkbytheContractorandSubcontractors;providedthattheContractorratherthantheOwnershallpayforsuchtestsandinspectionstotheextenttheydisclosedefectiveornonconformingWork.TheContractor’scostsincurredunderthisSection20.1shallbereimbursedaspartoftheCostoftheWork,excepttotheextentthedefectiveornonconformingWorkiscausedbythefaultofnegligencereferencedinSection6.6.TheContractorshallgivetheOwnerreasonablenoticeofthetimeforthetestsandinspectionsreferencedinthisSection业主应与第三方签约并支付承包商和分包商实施和完成工程所需的所有检测和检查费用；但如果这些检测和检查发现有缺陷或不符合要求的工程，则费用由承包商而不是业主支付。承包商根据本第20.1条发生的费用应作为工程费用的一部分予以补偿，但由于第6.6条规定的过失造成的缺陷或不合格的工程除外。承包商应向业主发出合理的通知，说明本第20.1条中规定的检测和检查的时间。20.2ObservationsorapprovalsbytheOwner,architectorothers(includingthirdparties)shallnotrelieveContractorofitssoleresponsibilityforconstructionmeans,methods,techniques,sequences,safetyissues,andprocedures,andforsupervising,coordinatingandperformingalloftheWork.20.2业主、建筑师或其他人（包括第三方）的观察或批准不应解除承包商对施工手段、方法、技术、顺序、安全问题和程序以及对监督、协调和实施所有工程的全部责任。21.As-BuiltDrawings.21.竣工图TheContractorshallmaintainduringtheprogressoftheWorkas-builtdrawingsindicatingthecurrentstatusoftheWorkasactuallyperformed.UponMechanicalCompletionoftheWork,theContractorshallprepareafinalversionofsuchas-builtdra