国际咨询工程师联合会fidic合同中英文对照版_secret

1、精选文档CONTENTS目 录1General Provisions一般规定81.1Definitions定义81.2Interpretation解释181.3Communications通信沟通191.4Law and Language法律和语言201.5Priority of Document文件优先次序211.6Contract Agreement合同协议书221.7Assignment权益转让221.8Care and Supply of Document文件的照管和供应231.9Confidentiality保密性231.10Employers Use of Contractors

2、Documents雇主使用承包商文件241.11Contractors Use of Employers Documents承包商使用雇主文件251.12Confidential Details保密事项261.13Compliance with Laws遵守法律261.14Joint and Several Liability共同的和各自的责任272The Employer雇主282.1Right of Access to the Site现场进入权292.2Permits, Licences or Approves许可、执照或批准302.3Employers personnel雇仆人员312

3、.4Employers Financial Arrangements雇主的资金支配322.5Employers Claims雇主的索赔323The Employers Administration雇主的管理343.1The Employers Representative雇主代表343.2The Employers personnel其他雇仆人员353.3Delegated Persons受托人员353.4Instructions指示373.5Determinations确定374The Contractor承包商394.1The Contractors General Obligations

4、承包商的一般义务394.2Performance security履约担保404.3Contractors Representative承包商代表434.4Subcontractors分包商444.5Nominated Subcontractors指定的分包商454.6Co-operation合作454.7Setting out放线474.8Safety procedures平安程序474.9Quality Assurance质量保证484.10Site Data现场数据494.11Sufficiency of the Contract Price合同价格494.12Unforeseeable

5、 Difficulties不行预见的困难504.13Rights of way and Facilities道路通行权于设施514.14Avoidance of Interference避开干扰514.15Access Route进场通路524.16Transport of Goods货物运输534.17Contractors Equipment承包商设备544.18Protection of the Environment环境爱护544.19Electricity, Water and Gas电、水和燃气544.20Employers Equipment and Free-Issue Mat

6、erial雇主设备和免费供应的材料554.21Progress Reports进度报告574.22Security of the Site现场保安594.23Contractors Operations on Site承包商的现场作业604.24Fossils化石615Design设计635.1General Design Obligations设计义务一般要求635.2Contractors Documents承包商文件645.3Contractors Undertaking承包商的承诺675.4Technical Standards and Regulations技术标准和法规675.5T

7、raining培训685.6As-Built Documents竣工文件695.7Operation and Maintenance Manuals操作和修理手册705.8Design Error设计错误706Staff and Labour员工716.1Engagement of Staff and Labour员工的雇用716.2Rates of Wages and Conditions of Labour工资标准和劳动条件726.3Persons in the Service of Employer为雇主服务的人员726.4Labour Laws劳动法726.5Working Hours

8、工作时间736.6Facilities for Staff and Labour为员工供应设施746.7Health and Safety健康和平安746.8Contractors Superintendence承包商的监督756.9Contractors Personnel承包商人员766.10Records of contractors Personnel and Equipment承包商人员和设备的记录776.11Disorderly Conduct无序行为777Plant, Materials and Workmanship生产设备、材料和工艺797.1Manner of Execut

9、ion实施方法797.2Samples样品807.3Inspection检验807.4Testing试验817.5Rejection拒收837.6Remedial Work修补工作847.7Ownership of Plant and Materials生产设备和材料的全部权857.8Royalties土地(矿区)使用费868Commencement,Delays and Suspension开工、延误和暂停878.1Commencement of Works工程的开工878.2Time for Completion竣工时间888.3Programme进度方案898.4Extension of

10、 Time for Completion竣工时间延长918.5Delays Caused by Authorities当局造成的延误928.6Rate of Progress工程进度928.7Delay Damages误期损害赔偿费948.8Suspension of Work临时停工948.9Consequences of Suspension暂停的后果958.10Payment for Plant and Materials in Event of Suspension暂停时对生产设备和材料的付款968.11Prolonged Suspension托长的暂停978.12Resumption

11、 of Work复工979Tests on Completion竣工试验989.1Contractors Obligations承包商的义务989.2Delayed Tests延误的试验1009.3Retesting重新试验1019.4Failure to Pass Tests on Completion未能通过竣工试验10110Employers Taking Over雇主的接收10310.1Taking Over of the Works and Sections工程和分项工程的接收10310.2Taking Over of Parts of the Works部分工程的接收10410.3

12、Interference with Tests on Completion对竣工试验的干扰10511Defects Liability缺陷责任10611.1Completion of Outstanding Work and Remedying Defects完成扫尾工作和修补缺陷10611.2Cost of Remedying Defects修补缺陷的费用10711.3Extension of Defects Notification Period缺陷通知期的延长10811.4Failure to Remedy Defects未能修补的缺陷10911.5Removal of Defectiv

13、e Work移出有缺陷的工程11011.6Further Tests进一步试验11111.7Right of Access进入权11111.8Contractor to Search承包商调查11211.9Performance Certificate履约证书11211.10Unfulfilled Obligations未履行的义务11311.11Clearance of Site现场清理11312Tests after Completion竣工后试验11512.1Procedure for Tests after Completion竣工后试验的程序11512.2Delayed Tests延

14、误的试验11612.3Retesting重新试验11712.4Failure to Pass Tests after Completion未能通过的竣工后试验11813Variations and Adjustments变更和调整12013.1Right to Vary变更权12013.2Value Engineering价值工程12113.3Variation Procedure变更程序12113.4Payment in Applicable Currencies以适用货币支付12313.5Provisional Sums暂列金额12313.6Daywork计日工作12413.7Adjust

15、ments for Changes in Legislation因法律转变的调整12613.8Adjustments for Changes in Cost因成本转变的调整12714Contract price and Payment合同价格和支付12814.1The Contract Price合同价格12814.2Advance payment预付款12914.3Application for Interim Payments期中付款的申请13114.4Schedule of Payments付款价格表13314.5Plant and Materials intended for the

16、Works拟用于工程的生产设备和材料13414.6Interim Payments期中付款13514.7Timing of Payments付款的时间支配13614.8Delayed Payment延误的付款13714.9Payment of Retention Money保留金支付13814.10Statement at Completion施工报表13914.11Application for Final Payment最终付款的申请14014.12Discharge结清证明14114.13Final Payment最终付款14114.14Cessation of Employers Li

17、ability雇主责任的中止14214.15Currencies of Payment支付的货币14315Termination by Employer由雇主终止14615.1Notice to Correct通知改正14615.2Termination by Employer由雇主终止14615.3Valuation at Date of Termination终止日期时的估价14915.4Payment after Termination终止后的付款15015.5Employers Entitlement to Termination雇主终止的权利15116Suspension and t

18、ermination by Contractor由承包商暂停和终止15216.1Contractors Entitlement to Suspend Work承包商暂停工作的权利15316.2Termination by Contractor由承包商终止15416.3Cessation of Work and Removal of Contractors Equipment停止工作和承包商设备的撤离15616.4Payment on Termination终止时的付款15717Risk and Responsibility风险和职责15717.1Indemnities保障15817.2Cont

19、ractors Care of the Works承包商对工程的照管15917.3Employers Risks雇主的风险16117.4Consequence of Employers Risks雇主风险的后果16217.5Intellectual and Industrial Property Rights学问产权和工业产权16317.6Limitation of Liability责任限度16518Insurance保险16618.1General Requirements for Insurances有关保险的一般要求16618.2Insurance for Works and Cont

20、ractors Equipment工程和承包商设备的保险17018.3Insurance against Injury to Persons and Damage to Property人身损害和财产损害险17318.4Insurance for Contractors Personnel承包商人员的保险17519Force Majeure不行抗力17719.1Definition of Force Majeure不行抗力的定义17719.2Notice of Force Majeure不行抗力的通知17919.3Duty to Minimise Delay将延误减至最小的义务18019.4C

21、onsequences of Force Majeure不行抗力的后果18019.5Force Majeure Affecting Subcontractor不行抗力影响分包商18119.6Optional Termination, Payment and Release自主选择终止、支付和解除18119.7Release from Performance under the Law依据法律解除履约18320Claims, Disputes and Arbitration索赔、争端和仲裁18420.1Contractors Claims承包商的索赔18420.2Appointment of t

22、he Dispute Adjudication Board争端裁决委员会的任命18820.3Failure to Agreement Dispute Adjudication Board对争端裁决委员会未能取得全都时19020.4Obtaining Dispute Adjudication Boards Decision取得争端裁决委员会的打算19120.5Amicable Settlement友好解决19420.6Arbitration仲裁19420.7Failure to Comply with Dispute Adjudication Boards Decision未能遵守争端裁决委员会

23、的打算19520.8Expiry of Dispute Adjudication Boards Appointment争端裁决委员会任命期满1961General Provisions一般规定1.1Definitions 定义In the Conditions of Contract (“these Conditions”), which include Particular Conditions and these General Conditions, the following words and expressions shall have the meaning stated. Wo

24、rds indicating persons or parties include corporation and other legal entities, except where the context requires otherwise.在合同条件（“本条件”），包括专用条件和通用条件中，下列词语和措辞应具有以下所述的含义.除上下文另有要求外，文中人员或当事各方等词语包括公司和其他合法实体.1.1.1The Contract合同1.1.1.1“Contract” means the Contract Agreement, these Conditions, the Employers

25、 Requirement, the Tender, and further document (if any) which are listed in the Contract Agreement.“合同”系指合同协议书、本条件、雇主要求、投标书和合同协议书列出的其他文件（假如有）.1.1.1.2“Contract Agreement” means the contract agreement referred to in Sub-Clause 1.6 Contract Agreement, including any annexed memoranda.“合同协议书”系指第1.6款合同协议书

26、中所述的合同协议书及所附各项备忘录.1.1.1.3“Employers requirements” means the document entitled employers requirements, as included in the Contract, and any additions and modifications to such document in accordance with the Contract. Such document specifies the purpose, scope, and/or design and/or other technical cr

27、iteria, for the Works. “雇主要求”系指合同中包括的，题为雇主要求的文件，其中列明工程的目标、范围、和（或）设计和（或）其他技术标准，以及按合同对此项文件所作的任何补充和修改.1.1.1.4“Tender” means the Contractors signed offer for the Works and all other documents which the Contractor submitted therewith (other than these Conditions and Employers Requirements, if so submitte

28、d), as included in the Contract.“投标书”系指包含在合同中的由承包商提交的为完成工程签署的报价，以及伴同提交的全部其他文件（本条件和雇主要求除外，犹如时提交）.1.1.1.5“Performance Guarantees” and “Schedule of payments” mean the documents so named (if any), as included in the Contract.“履约保证”和“付款方案表”系指合同中包括的具有上述名称的文件（假如有）.1.1.2Parties and Persons各方和人员1.1.2.1“Party

29、” means the Employer or the Contractor, as the context requires.“当事方（或一方）”依据上下文需要，或指雇主，或指承包商。1.1.2.1“Employer” means the person named as employer in the Contract Agreement and the legal successors in title to this person.“雇主”系指在合同协议书中被称为雇主的当事人及其财产全部权的合法继承人。1.1.2.3“Contractor” means the person(s) nam

30、ed as contractor in the Contract Agreement and the legal successors in title to this person(s).“承包商”系指合同协议书中被称为承包商的当事人及其财产全部权的合法继承人。1.1.2.4“Employers Representative” means the person named by the Employer in the Contract or appointed from time to time by the Employer under Sub-Clause 3.1 the Employe

31、rs Representative, who acts on behalf of the Employer.“雇主代表”系指由雇主在合同中指名的人员，或有时由雇主依据第3.1款雇主代表的人员的规定任命为其代表的人员。1.1.2.5“Contractors Representative” means the person named by the Contractor in the Contract or appointed from time to time by the Contractor Sub-Clause 4.3 the Contractors Representative, who

32、 acts on behalf of the Contractor.“承包商代表”系指由承包商在合同中指名的人员，或有时由承包商依据第4.3款承包商代表的规定任命为其代表的人员。1.1.2.6“Employers Personnel” means the Employers Representative, the assistants referred to in Sub-Clause 3.2 Other Employers Personnel and all other staff, labour and other employees of the Employer and of the

33、Employers Representative; and any other personnel notified to the Contractor, by the Employer or the Employers Representative, as Employers Personnel.“雇仆人员”系指雇主代表、第3.2款其他雇仆人员中提到的助手、以及雇主和雇主代表的全部其他职员、工人和其他雇员，以及雇主或雇主代表通知承包商作为雇仆人员的任何其他人员。1.1.2.7“Contractors Personnel” means the Contractors Representativ

34、e and all personnel whom the Contractor utilizes on Site, who may include the staff, labour and other employees of the Contractor and of each Subcontractor, and any other personnel assisting the Contractor in the execution of the works.“承包商人员”系指承包商代表和承包商在现场聘用的全部人员，包括承包商和每个分包商的职员、工人和其他雇员，以及全部其他挂念承包商实

35、施工程的人员。1.1.2.8“Subcontractor” means any person named in the Contract as a subcontractor, or any person appointed as a subcontractor, for a part of the Works; and the legal successors in title to each of these persons.“分包商”系指为完成部分工程，在合同中指名为分包商、或被任命为分包商的任何人员，以及这些人员财产全部权的合法继承人。1.1.2.9“DAB” means the pe

36、rson or three persons so named in the Contract, or other person(s) appointed under Sub-Clause 20.2 Appointment of the Dispute Adjudication Board or Sub-Clause 20.3 Failure to Agree Dispute Adjudication Board.“DAB（争端裁决委员会）”系指在合同中如此指名的一名或三名人员，或依据第20.2款争端裁决委员会的任命或第20.3款对争端裁决委员会未能取得全都的规定任命的其他人员。1.1.2.10

37、“FIDIC” means the Federation International des Ingenieurs-Conseils, the international federation of consulting engineers. “菲迪克（FIDIC）”系指国际询问工程师联合会。1.1.3Dates ,Test, Periods and Completion日期、试验、期限和竣工1.1.3.1“Base Date” means the date 28 days prior to the latest date for submission of the Tender.“基准日期”

38、系指递交投标书截止前28天的日期。1.1.3.2“Commencement Date” means the date notified under Sub-Clause 8.1 Commencement of Works, unless otherwise defined in the Contract Agreement.“开工日期”系指依据第8.1款工程的开工的规定通知的日期，合同协议书中另有规定的除外。1.1.3.3“Time for Completion” means the time for completing the Works or a Section (as the case

39、 may be) under Sub-Clause 8.2 Time for Completion, as stated in the Particular Conditions (with any extension under Sub-Clause 8.4 Execution of Time for Completion), calculated from the Commencement Date. “竣工时间”系指专用条件中规定的，自开工日期算起，至工程或某分项工程（视状况而定）依据第8.2款竣工时间规定的要求竣工（连同依据第8.4款竣工时间的延长的规定提出的任何延长期）的全部时间。1

40、.1.3.4“Tests on Completion” means the tests which are specified in the Contract or agreed by both Parties or instructed as a Variation, and which are carried out under Clause 9 Tests on Completion before the works or a Section (as the case may be) are taken over by the Employer.“竣工试验”系指在合同中规定或双方商定的，

41、或按指示作为一项变更的，在工程或某分项工程（视状况而定）被雇主接收前，依据第9条竣工试验的要求，进行的试验。1.1.3.5“Taking-Over Certificate” means a certificate issued under Clause 10 Employers Taking Over. “接收证书”系指依据第10条雇主接收的规定颁发的证书。1.1.3.6“Tests after Completion” means the tests (if any) are specified in the Contract and which are carried out under C

42、lause 12 Tests after Completion after the works or a Section (as the case may be) are taken over by the Employer.“竣工后试验”系指在合同中规定的，在工程或某分项工程（视状况而定）被雇主接收后，依据第12条竣工后试验的要求，进行的试验（假如有）。1.1.3.7“Defects Notification Period” means the period for notifying defects in the Works or a Section (as the case may be

43、) under Sub-Clause 11.1 Completion of Understanding Works and Remedying Defects, as stated in the Particular Conditions (with any extension under Sub-Clause 11.3 Extension of Defects Notification Period), calculated from the date on which the Works or Section is competed as certified under Sub-Claus

44、e 10.1 Taking Over of the Works and Sections. If no such period is stated in the Particular Conditions, the period shall be one year.“缺陷通知期限”系指专用条件中规定的，自工程或某分项工程（视状况而定）依据第10.1款工程和分项工程的接收的规定证明的竣工日期算起，至依据第11.1款完成扫尾工作和修补缺陷的规定通知工程或分项工程存在缺陷的期限（连同依据第11.3款缺陷通知期限的延长的规定提出的任何延长期）。假如专用条件中没有提出这一期限，该期限应为一年。1.1.3

45、.8“Performance Certificate” means the certificate issued under Sub-Clause 11.9 Performance Certificate.“履约证书”系指依据第11.9款履约证书的规定颁发的证书。1.1.3.9“day” means a calendar day and “year” means 365 days.“日（天）”系指一个日历日，“年”系指365天。1.1.4Money and Payments款项与付款1.1.4.1“Contract Price” means the agreed amount stated i

46、n the Contract Agreement for the design, execution and completion of the Works and the remedying of any defects, and includes adjustment (if any) in accordance with the contract.“合同价格”系指在合同协议书中写明的、经商定的工程设计、施工、竣工和缺陷修补的款额，包括以及依据合同做出的调整（假如有）。1.1.4.2“Cost” means all expenditure reasonably incurred (or t

47、o be incurred) by the Contractor, whether on or off the Site, including overhead and similar charges, but does not include profit.“成本（费用）”系指承包商在现场内外所发生（或将发生）的全部合理开支，包括管理费用及类似的支出，但不包括利润。1.1.4.3“Final Statement” means the statement defined in Sub-Clause 14.11Application for Final Payment.“最终报表”系指第14.1

48、1款最终付款的申请规定的报表。1.1.4.4“Foreign Currency” means a currency in which part (or all) of the Contract Price is payable, but not the Local Currency.“外币”系指可用于支付合同价格中部分（或全部）款项的当地货币以外的某种货币。1.1.4.5“Local Currency” means the currency of the Country.“当地货币”系指工程所在国的货币。1.1.4.6“Provisional Sum” means a sum (if any)

49、 which is specified in the Contract as a provisional sum, for the execution of any part of the Works or for the supply of Plant, Material or services under Sub-Clause 13.5 Provisional Sums.“暂列金额”系指合同中规定作为暂列金额的一笔款额（假如有），依据第13.5款暂列金额的规定，用于工程某一部分的实施，或用于供应生产设备、材料或服务。1.1.4.7“Retention Money” means the ac

50、cumulated retention moneys which the Employer retains under Sub-Clause 14.3 Application for Interim Payments and pays under Sub-Clause 14.9 Payment of Retention Money.“保留金”系指雇主依据第14.3款期中付款的申请的规定扣留的保留金累计金额，依据第14.9款保留金的支付的规定进行支付。1.1.4.8“Statement” means a statement submitted by the Contractor as part

51、of an application for payment under Clause 14 Contract Price and Payment.“报表”系指承包商依据第14条合同价格和付款的规定提交的作为付款申请的组成部分的报表。1.1.5Works and Goods工程和货物1.1.5.1“Contractors Equipment” means all apparatus, machinery, vehicles and other things required for the execution and completion of the Works and remedying o

52、f any defects. However, Contractors Equipment excludes Temporary Works, Employers Equipment (if any), Plant, Materials and any other things intended to form or forming part of the Permanent Works.“承包商设备”系指为实施和完成工程、以及修补任何缺陷需要的全部仪器、机械、车辆和其他物品。但承包商设备不包括临时工程、雇主设备（假如有）、以及拟构成或正构成永久工程一部分的生产设备、材料和其他任何物品。1.1

53、.5.2“Goods” means Contractors Equipment, Materials, Plant and Temporary Works, or any of them as appropriate.“货物”系指承包商设备、材料、生产设备和临时工程，或视状况其中任何一种。1.1.5.3“Materials” means things of all kinds (other than Plant) intended to form or forming part of the Permanent Works, including the supply-only material

54、s (if any) to be supplied by the Contractor under the Contract.“材料”系指拟构成或正构成永久工程一部分的各类物品（生产设备除外），包括依据合同要由承包商供应的只供材料（假如有）。1.1.5.4“Permanent Works” means the permanent works to be designed and executed by the Contractor under the Contract.“永久工程”系指依据合同承包商要进行设计和施工的永久性工程。1.1.5.5“Plant “means the apparatu

55、s, machinery and vehicles intended to form or forming part of the Permanent Works.“生产设备”系指拟构成或正构成永久工程一部分的仪器、机械和车辆。1.1.5.6“Section” means a part of the Works specified in the Particular Conditions as a Section (if any).“分项工程”系指在专用条件中确定为分项工程（假如有）的工程组成部分。1.1.5.7“Temporary Works” means all temporary works of every kind (other than Contractors Equipment) required on Site for the execution and completion of the Permanent Works and the remedying of any defects.“临时工程”系指为实施和完成永久工程及修补任何缺陷，在现场所需的全部各类临时性工程（承包商设备除外）。1.1.5.8“Works” means t